Loading...
86-0214 Halloran and Yauch 0X14 THE AMERICAN INSTITUTE OF ARCHITECTS , -0e11:=4 ,stAv-vt, N-14? AIA Document A101 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a STIPULATED SUM 1977 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION Use only with the 1976 Edition of AM Document A201, Genera/ Conditions of the Contract for Construction. This document has been approved and endorsed by The Associated General Contractors of America. AGREEMENT made as of the Fourteenth day of February in the year of Nineteen Hundred and Eight-six BETWEEN the Owner: City of Elgin 150 Dexter Court Elgin, IL 60120 and the Contractor: Halloran & Yauch, Inc. 2040 Lehigh Avenue Glenview, IL 60025 The Project: Elgin Municipal Golf Course The Architect: Killian Design Group, Inc. 639 First Bank Drive Palatine, IL 60067 The Owner and the Contractor agree as set forth below. Copyright 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, © 1977 by the American Institute of Architects, 1735 New York Avenue, N.W., Washington, D. C. 20006. Reproduction of the material herein or substantial quotation of its provisions without permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 1 ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, all Addenda issued prior to and all Modifications issued after exe- cution of this Agreement. These form the Contract, and all are as fully a part of the Contract as if attached to this Agreement or repeated herein. An enumeration of the Contract Documents appears in Article 7. ARTICLE 2 THE WORK The Contractor shall perform all the Work required by the Contract Documents for (Here insert the caption descriptive of the Work as used on other Contract Documents.) Installation of Pump Stations Remodeling ARTICLE 3 TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION The Work to be performed under this Contract shall be commenced within 10 days of• awa rd of . Contract, and, subject to authorized adjustments, Substantial Completion shall be achieved not later than (Here insert any special provisions for liquidated damages relating to failure to complete on time.) April 15, 1986. No penalty clause is included herein. MA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 2 ARTICLE 4 CONTRACT SUM The Owner shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order as provided in the Contract Documents, the Contract Sum of Seventy-five thousand six hundred ninety and No/100 dollars ($75,690.00) The Contract Sum is determined as follows: (State here the base bid or other lump sum amount,accepted alternates,and unit prices,as applicable.) Contractor's Proposal dated January 29, 1986: Schedule A - East Pump Station $38,800 Schedule B - West Pump Station 23,600 Schedule C - 3" PVC supply line 11 ,800 Our letter dated January 30, 1986 Rewiring of the well from the new pump location 1 ,490 Total $75,690 ARTICLE 5 PROGRESS PAYMENTS Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as pro- vided in the Contract Documents for the period ending the day of the month as follows: Not later than days following the end of the period covered by the Application for Payment percent ( %) of the portion of the Contract Sum properly allocable to labor, materials and equipment incorporated in the Work and percent ( %) of the portion of the Contract Sum properly allocable to materials and equipment suitably stored at the site or at some other location agreed upon in writing,for the period covered by the Application for Payment, less the aggregate of previous payments made by the Owner; and upon Substantial Completion of the entire Work, a sum sufficient to increase the total payments to percent ( %) of the Contract Sum, less such amounts as the Architect shall determine for all incomplete Work and unsettled claims as provided in the Contract Documents. (If not covered elsewhere in the Contract Documents,here insert any provision for limiting or reducing the amount retained after the Work reaches a certain stage of completion.) Rawt nos-dt -and-unpaid-u.R4§3 -the-contract•Documeats.shallbear—interesi4ro The-elate -Fate wale red_bel.ciw, o.r--is-tbe.absencebereof,at.the-legal-rate-prevailar g at-the-place-of-tJae Pioojert. (;IFre Th ey-ratc o41Merest-agree4 tlpow.} (Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Contractor's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should be obtained with respect to deletion, modification, or other requirements such as written disclosures or waivers.) AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 3 f M ARTICLE 6 FINAL PAYMENT Final payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by the Owner to the Contractor when the Work has been completed, the Contract fully performed, and a final Certificate for Payment has been issued by the Architect. ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 Terms used in this Agreement which are defined in the Conditions of the Contract shall have the meanings designated in those Conditions. 7.2 The Contract Documents,which constitute the entire agreement between the Owner and the Contractor,are listed in Article 1 and, except for Modifications issued after execution of this Agreement, are enumerated as follows: (List below the Agreement,the Conditions of the Contract(General,Supplementary,and other Conditions),the Drawings,the Specifications,and any Addenda and accepted alternates,showing page or sheet numbers in all cases and dates where applicable.) Standard Form of Agreement between owner and contractor dated February 14, 1986 Bid Proposal Form, pages 1 & 2, dated January 29, 1986 Addendum #1 , Items 1-5, dated January 14, 1986 (Item 6 is excluded) Contractor's letter, dated February 5, 1986 100% Performance Bond in accordance with Paragraph 11 of this invitation to Bid Section of the Project Specifications. Certificate of Insurance in accordance with Paragraph 12 of the invitation to Bid Section of the Project Specifications. Project Specifications Book, dated January 6, 1986 Project Drawings, Sheets 1-4, dated October 14, 1985 This Agreement entered into as of the day and year first written above. OWNER CONTRACTOR Cit Elgin Halloran & Yauch, Inc. • By: g�----���vrl s, ‘.. GIS rS i.1 tle: City v:nager it1 /: )A� �1 AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 4 • " - • Bond No • Fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 Performance Bond KNOW ALL MEN BY THESE PRESENTS: That HALLORAN & YAUCHt INC. (Here insert the name and address or legal title of the Contractor) 2040, Lehigh, .Glenview,. 111 .60025 as Principal, hereinafter called Contractor, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corpora- tion of the State of Maryland, with its home office in the City of Baltimore, Maryland, U. S. A., as Surety, hereinafter called Surety, are held and firmly bound unto CFTYI. ELGLN 150 Dexter Ct. Elgin„ 111 ,60120 (Here insert the name and address or legal title of the Owner) as Obligee, hereinafter called Owner, in the amount of SEVENTY FIVE THOUSAND SIX HUNDRED NINETY & . _ , „......... ..„---.. . Dollars (S 754690,00 ), for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated February 14 entered into a contract with Owner for. _INSTALLATION...0E pump STATIONS R-ET1GDELING ELGIN MUNICIPAL GOLF COURSE in accordance with drawings and specifications prepared by. KILLIAN -DESIGN---GR-OUP„-INC. 639 First Bank Dr, Palatine, .111.60067 (Here insert full name,title and address) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said contract, then this obligation shall be null and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall promptly (1) Complete the Contract in accordance with its terms and conditions, or (2) Obtain a bid or bids for completing the Contract in accordance with its terms and condi- tions, and upon determination by Surety of the lowest responsible bidder, or, if the Owner elects, upon determination by the Owner and Surety jointly of the lowest responsible bidder, arrange for a contract between such bidder and Owner, and make available as work progresses (even though there should be a default or a succession of defaults under the contract or contracts of completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the contract price," as used in this para- graph, shall mean the total amount payable by Owner to Contractor under the Contract and any amendments thereto, less the amount properly paid by Owner to Contractor. Any suit under this bond must be instituted before the expiration of two (2) years from the date on which final payment under the contract falls due. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the heirs, executors, administrators or successors of Owner. Signed and sealed this 28th day of 19...86 In the presence of: ' ORAN & .YAUCH, LNC. (SEAL) Princip9:1; xkiim t•stRA1) x Title FIDELITY AN )EPOSIT COMPANY OF MARYLAND .(SEAL) Title ROBERT D. JACO(ON ATTORNEY IN FACT c3091— Approved by The American Institute of Architects,A.I.A.Document No.A-311 February 1970 Edition. Fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE Performance Bond No ON BEHALF OF TO • • • Bond No Fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 Labor and Material Payment Bond Note: This bond is issued simultaneously with Performance Bond in favor of the owner conditioned on the full and faithful performance of the contract. KNOW ALL MEN BY THESE PRESENTS: That HALLORAN &. YAUCH,... INC. .(Here insell,the nae and address or legal title of the Contractor) 2040 Lehigh, Glenview, Ill . 60025 as'Principal, hereinafter called Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corpora- tion of the State of Maryland, with its home office in the City of Baltimore, Maryland, U. S. A., as Surety, hereinafter called Surety, are held and firmly bound unto CITY OF ELGIN_ 150 Dexter Ct. Elgin,I11 .60120 (Here insert the name and address or legal title of the Owner) as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined, in the amount of SEVENTY FIVE THOUSAND SIX HUNDRED NINETY & NO/100 (Here insert a sum equal to at least one-half of the contract price) Dollars ($_../5,690.00 ), for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by written agreement dated February 14 entered into a contract with Owner for INSTALLATION OF PUMP STATIONS-REMODELING ELGIN MUNICIPAL GOLF COURSE in accordance with drawings and specifications prepared by -KILLIAN. DESIGN OROUR,INC. 639 First Bank Dr. Palatine, Ill. 60_067 (Here insert full name,title and address) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. NO\V, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make pay- ment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract,then this obligation shall be void;otherwise it shall remain in full force and effect,subject, however, to the following conditions: 1. A claimant is defined as one having a direct contract with the Principal or with a sub-contractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the contract, labor and material being construed to include that part of water,gas, power, light, heat, oil,gasoline, telephone service or rental of equipment directly applicable to the Contract. 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined,who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such claimant's work or labor was done or performed, or materials were furnished by such claimant, may sue on this bond for the use of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any claimant: (a) Unless claimant, other than one having a direct contract with the Principal, shall have given written notice to any two of the following:The Principal, the Owner,or the Surety above named, within ninety (90) days after such claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished,or for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope addressed to the Principal, Owner or Surety, at any place where an office is regularly main- tained for the transaction of business,or served in any manner in which legal process may be served in the state in which the aforesaid project is located,save that such service need not be made by a public officer. (b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract, it being understood,however,that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law. (c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project,or any part thereof,is situated,or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith here- under, inclusive of the payment by Surety of mechanics' liens which may be filed of record against said improvement, whether or not claim for the amount of such lien be presented under and against this bond. Signed and sealed this 28th day of In the presence of: HAL ORAN_S_YAUCH,-INC, (SEAL) (11 Principal Title FIDELITY A DEPOSIT COMPANY OF MARYLAND - 11 Title (SEAL) By. ,e2 ROBERT D. JACOBSON ATTORNEY IN FACT C309eX— Approved by The American Institute of Architects,A.I.A.Document No.A-311 February 1970 Edition. Fidelity and Deposit Company HOME OFFICE OF MARYLAND BALTIMORE Labor and Material . Payment Bond No $ ON BEHALF OF TO STATE OF ILLINOIS • , ` COUNTY OF COOK I a`' 1. - MAR.Y..AN.N__PDIELL a Notary Public in and for the state and county afore- said, do hereby certify that ROB.E.RT 4. JACQBSQN of the __._._ - _E IDF1.I_T_Y_.MD_.DEPQ5I T COMPANYOF MARYLAND who is personally known to me, appeared before me this day and acknowledged that he aig-ned, sealed and delivered the foregoing instrument as his free and voluntary act as ATTORNEY I fJ FACT --._----- _______.__ of the_._EI.DLL_ITY..A.N.0..D PQSIT_.C.QMPANY OF MARYLAND .... and as the free and voluntary act of the......._--___EI_DELJTY_AND_.D.E_KaIT._GQM.?A.NY__QF_ ARYLAND__._ ---------------- , for the,uses and purpos th rein set forth. p Given under my hand and Notarial Seal this .. day of -�^— .. A. D. 19.0".49-- • _-_d _ ____..... ... 10-28-87 M3 commission _ - Notary Publicup'uea___.:�__...�___:_> NOTARIAL JURAT FK 230 8-64 5M ♦RINTLO IN U.S.A- Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE BALTIMORE MO KNOW ALL MEN BY THESE PRESENTS: That the FIDELITI AND DEPOSIT COMP ANN of N1\R11.k's D,a corporation of Ilir State of Maryland. by C. M. PECOT, JR. , Vice-President, and C. W. ROBBINS Assistant Secretary,:n pursuance of authority granted by Article VI,Section 2.of the By-Laws of said Company,which reads as follows: ''The Chairman of the Board. or the President• or any Executive Vice-President. or any of the Senior \ire-President.or \n c l'ressdents specially authorized so ludo b,the Board of Directors orbs the Executive Committee,shall have power.bv and with the concurrence of the fir,retars or any one of the Assistant Secretaries.to appoint Resident Vice-Presidents. Assistant \ice-Precedent.and Anornevs iii Fart a.the hu.nle.s the Company may require. or to authorize any person or persons to execute oil behalf of the Compare any bonds. undertakings, reg ognlzanre.- stipulations.policies.contracts,agreements.deeds,and releases and assignments of Judgements.decrees.mortgages and instruments ul the'wore sit mortgages.... and to affix the seal of the Company thereto.- does hereby nominate constitute and appoint Robert D. Jacobson, Jack D. Ianiphier, Thome J. Connolly, Thomas L. McClanahan, Maryann Wilson and Mary A. Powell, all of Park Ridge, Illinois, MACH its true and lawful agent and Attorney-in-Fact,to make,execute,seal and deliver,for,and on its behalf as surety,and as its act and deed: any and all bonds and undertakings n. t e execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Company,as fully and amply,to all intents and purposes,as if they had been duly executed and acknowledged by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper persons. This power of attorney revokes that issued on behalf of Robert D. Jacobson, etal, dated, July 22, 1980. The said Assistant Secretary does hereby certify that the aforegoing is a true copy of Article VI,Section 2,of the Bylaws of said Company,and is now in force. IN WITNESS WHEREOF,the said Vice-President and Assistant Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 24th day of September , A.D. 19 8k. FIDELITY AND DEPOSIT COMPANY OF MARYLAND y ' Poe. ATTEST: SEAL By 8414'4L Alssiston:Secretary Vice-President STATE OF MARYLAND SS: Civ OF BALTIMORE On this 24th day of September ,A.D. 19 84,before the subscriber,a Notary Public of the State of Maryland,in and for the City of Baltimore,duly commissioned and qualified,came the above-named Vice-President and Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND.tome personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same,and being by me duly sworn,severally and each for himself deposeth and saith,that they are the said officers of the Company aforesaid,and that the seal affixed to the preceding instrument is the Corporate Seal of said Company,and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed by Official Seal,at the City of BJltimore,the day and year fi t above written. o;iy.rur'�. •}si Notary Public Commsion Expires.-Jolly 1 a--19$6. CERTIFICATE I,the undersigned, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the original Power of Attorney of which the foregoing is a full,true and correct copy,is in full force and effect on the date of this certificate:and I do further certify that the Vice-President who executed the said Power of Attorney was one of the additional Vice-Presidents specially authorized by the Board of Directors to appoint any Attorney-in-Fact as provided in Article VI,Section 2 of the By-Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969. RESOLVED:"That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company,whether made heretofore or hereafter,wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed.' IN TESTIMONY W EOF, I have hereunto sub ribed my name and affixed the corporate seal of the said Company,this W day of19.1G 114.29.—Cd036-0382 Assistant Seer FOR YOUR PROTECTION I,OOK FOR "I'IIE F&I) WATER\IARK Certificate of Insurance THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON YOU THE CERTIFICATE HOLDER.THIS CERTIFICATE IS NOT AN INSURANCE POLICY AND DOES NOT AMEND,EXTEND,OR ALTER THE COVERAGE AFFORDED BY THE POLICIES LISTED BELOW. This is to Certify that - _ LIBERTY = { Name and =_ Halloran & Yauch, Inc. & H & Y Mfg. 4.4a address of MUTUAL 2040 Lehigh Avenue Insured. Mf« Muni M M uttn,Muiu T` ,N URA COMPANY Glenview, Illinois 60025 is, at the issue date of this certificate, insured by the Company under the policy(ies)listed below. *The insurance afforded by the listed polrcy(tes)is subject to all their terms,exclusions and conditions and is not altered by any requirement,term or condition of any contract or other document with respect to which this certificate may be issued. TYPE OF POLICY CERT. EXP. DATE POLICY NUMBER LIMITS OF LIABILITY COVERAGE AFFORDED UNDER W.C. COV. B LAW OF THE FOLLOWING STATES: BODILY INJURY BY ACCIDENT WORKERS' $500,000 EA. ACCIDENT 12/31/86 WC2-141-015996-175 Illinois BODILY INJURY BY DISEASE COMPENSATION $500,000 EA. PERSON BODILY INJURY BY DISEASE $500,000 POLICY LIMIT ® aR COMPREHENSIVE BODILY INJURY PROPERTY DAMAGE ❑ SCHEDULE FORM $ 500,000 OCCEACH EACH URRENCE $ 250,000 OCCURRENCE �y PRODUCTS COM- A F LETED OPERATIONS $ 5'00,000 AGGREGATE $ 250,000 AGGREGATE CY J L— 12/31/86 LG1-141-015996-115 LZ' Q INDEPENDENT CON- COMBINED SINGLE LIMIT 0= ( J TRACTORS.'CONTRAC- BODILY INJURY AND PROPERTY DAMAGE TORS PROTECTIVE $ X EACH OCCURRENCE I�55 CONTLITYRACTUAL $ X AGGREGATE LIABI ll Broad Form Comprehensive General Liability 01- OWNED $ 790,000 EACH ACCIDENT-SINGLE LIMIT-B.I. AND P.D. COMBINED ® NON-OWNED 12/31/86 AS1-141-015996-095 $ X EACH PERSON Q Q LXJ EACH ACCIDENT EACH ACCIDENT HIRED $ X OR OCCURRENCE $ X OR OCCURRENCE Umbrella w Excess 12/31/86 TF1-141-015996-195 $2,000,000 Combined Single Limit m Liability — 0 LOCATION(S)OF OPERATIONS&JOB#(If Applicable) DESCRIPTION OF OPERATIONS: Project: Elgin Municipal Golf Course *NOTE You will NOT be not tied annually of the connnuation of this coverage You will be notified if this coverage is terminated or reduced NOTICE OF CANCELLATION: THE COMPANY WILL NOT TERMINATE OR REDUCE THE INSURANCE AFFORDED UNDER THE ABOVE POLICIES UNLESS XX DAYS NOTICE OF SUCH TERMINATION OR REDUCTION HAS BEEN MAILED TO: City of Elgin 150 Dexter Court AUTHORIZED REPRESENTATIVE CERTIFICATE Elgin, IL 60120 HOLDER-i 2/27/86 Des Plaines, IL DATE ISSUED OFFICE L Th,cert:f,cme is e,ec ted Li LIBFRTY MUTUA INSURANCE COMPAN,m'espects such•'s -ance os an afforded t, Tha•Cu'nos^. e e+er •t•r,by LBEPTv bT JTUA,FRE INS'iPAtr.7E COMA.,. o=. respect•such 3rso-ance a<_'s of o'ded b,Tnn'Compae, •is ececured or tiBERIY INSURANCE CORPORATION o,resoe-t•sur, ins,,' as is attorded b,T•-j•Comport BS 745 RI