HomeMy WebLinkAbout90-0215 Kane KCCDAP Grant 90- t) 15
AGREEMENT
BETWEEN THE COUNTY OF KANE
AND THE CITY OF ELGIN
This AGREEMENT is entered into as of the - day of
, 1990 , by and between the County OF KANE,
(hereinafter called "COUNTY") , and the City of Elgin (hereinafter
called "GRANTEE") having a principal place of business at. 150
Dexter Court , Elgin , IL 60120
I . RECITALS
A. COUNTY has created through Kane County Board Resolution
88-101 the Kane County Community Development Assistance
Program (hereinafter called the "KCCDAP") .
B. GRANTEE is eligible to apply for a KCCDAP Grant pursuant
to the established KCCDAP guidelines and has submitted
an application for a grant wherein all project
activities therein described are eligible activities for
KCCDAP funding.
C. COUNTY has considered and approved the application of
GRANTEE and agrees to distribute an amount not to exceed
one houndred thousand dollars ($100 ,000. 00) (hereinafter
"Grant Funds") to GRANTEE upon conditions provided
herein.
D. The COUNTY and GRANTEE enter into this Agreement
pursuant to their respective powers to enter into such
Agreements , as those powers are defined in the Illinois
Constitution and applicable statutes .
II . SCOPE OF PROJECT
A. Grantee hereby agrees to perform. in a timely fashion ,
the following activity. as previously defined in the
application and project description submitted by the
GRANTEE: Riverfront Redevelopment II and III
hereinafter "PROJECT") .
B. The description of the Project stated hereinabove is not
necessarily inclusive , and it is further outlined in
GRANTEE 's application and project description , and as
described in Exhibit "A" attached hereto, incorporated
herein and made a part of this Agreement.
C. This Project shall be identified as KCCDAP Account No.
8902011 which identifying number shall be used by
GRANTEE on all payment requests.
III . GRANTEE ' S COMPLIANCE WITH GENERAL REQUIREMENTS
A. GRANTEE acrees and authorizes Kane County Development
Department to conduct on-site reviews, to examine
personnel and employment records and to conduct any
other procedures or practices to assure compliance with
the provisions of this Agreement.
3. GRANTEE acrees not to violate any laws , state or federal
rules or reculaticns regard-ng a direct or indirect
illegal interest on the part of any employee or elected
official of the GRANTEE in the Project or payments made
pursuant to this Agreement.
C. GRANTEE shall maintain records to show actual time
devoted and costs incurred, in relation to the Project,
and shall prepare and submit quarterly progress reports
which describe the work already performed and
anticipated during the remaining time of the Project.
Upon fifteen ( 15) days notice from the COUNTY, originals
or certified copies of all time sheets, billings , and
other documentation used in the preparation of said
progress reports shall be made available for inspection,
copying, or auditing by the COUNTY at any time during
normal business hours .
D. GRANTEE shall not discriminate against any employee or
applicant for employment because of race, color,
religion, sex, Cr national origin. All subcontracts
must contain the following equal opportunity clause and
also stipulate that such clause be posted in some form
on the job site : The Contractor shall not discriminate
against any employee or applicant for employment because
of race, color religion, sex, or national origin.
Further, the GRANTEE shall conform itself to and comply
with all applicable provisions of the Illinois Human
Rights Act, Illinois Revised Statutes , ch. 68 , para 1-101
( 19 87 ) as amended . •
IV. SPECIAL CONDITIONS
COUNTY may withhold all or any portion of Grant Funds until
such time as when it can be satisfactorily determined by COUNTY
that GRANTEE has met certain special conditions, if applicable
and as set forth in Appendix "3" attached hereto, incorporated
herein and mace a part of this Agreement.
V. RIGHTS TO SUBCONTRACT •
A. GRANTEE may at its sole option subcontract all or any
portion of the Project to such engineers, architects,
independent land use consultants , professional land
planner, construction contractors or other entities as
GRANTEE shall deem appropriate Cr necessary and upon
such terms as may be acceptable to GRANTEE.
3. GRANTEE will be responsible for assembling bid packages
or requests for proposal , where applicable, and shall
comply with any and all local , state and federal
requirements relative to public notice, bid opening and
bid acceptance.
VI. BILLING PROCEDURE
A. COUNTY shall make disbursements to the GRANTEE as either
reimbursement for advances made by GRANTEE or as
advances for specific cash requirements of GRANTEE.
Whether for reimbursement or advancement, GRANTEE shall
comply with the following requirements :
( 1) GRANTEE shall submit claims with an accompanying
list itemizing all disbursements of Grant Funds , on
a form provided by the COUNTY;
( 2) COUNTY will disburse to GRANTEE no more than 50%
( f_f t•' percent) of total dollars for the completion
of any one activity and listing of disbursements
accompanying claim will indicate actual breakdown
of financial responsibility.
(3 ) Any claim for advancement of Grant Funds shall be
limited to an amount necessary for GRANTEE to meet
specific cash requirements for the project and
shall be disbursed by GRANTEE within ten (10)
• working days of receipt by GRANTEE;
(4 ) Any request for reimbursement or advancement
pertaining to work under subcontracts shall include
GRANTEE ' s certification as follows :
(A) For interim payments to the subcontractor,
that the work for which payment is requested
has been performed and is in place and to the
best of GRANTEE ' s knowledge, information and
belief that, the quality of such work is in
accordance with the subcontract , subject to :
( i) any evaluation of such work as a
functioning project upon substantial
completion; ( ii) the results of any subsequent
tests permitted by the subcontract; and (iii)
any defects or deficiencies not readily
apparent upon inspection of the work; and
(b) For final payment, that the work has been
completed , accepted by GRANTEE and performed
n a satisfactory manner and in conformance
with the subcontract.
(5) GRANTEE shall forward to COUNTY copies of all
billings, vouchers, and other documents
representing any accounts payable, in such timely
and reasonable manner as both parties shall
determine.
B. Immediately upon submission of a claim for Grant Funds ,
COUNTY shall process such claim and shall approve such
claim for payment pursuant to Kane County Board policy,
as amended .
C. COUNTY shall be responsible, except as provided for in
Sections VIII and IX hereof , for paving all required
payments against expenses incurred by GRANTEE under this
Agreement.
VII. ADMINISTRATION AND REPORTING .RZQU_TRNTS
A. GRANTEE shall administer the Grant Funds in accordance
with sound fiscal management and accountability
practices as prescribed by Article B, Section 4 of the
Illinois Constitution (1970) and all laws pursuant
thereto.
3. All GRANTEE and KCCDAP funds shall be placed in, and
expended from, a separate non- interest bearing checking
account.
C. GRANTEE shall :
(1 ) Maintain financial records adequate for auditing
and reporting requirements .
(2) Prepare a financial report at least quarterly of
the revenues and expenditures of the Grant Proj ect,
and prepare a summary report within 90 days of
completion of the project .
( 3 ) Have supporting documentation available for County
inspection, copying or auditing purposes . GRANTEE
shall permit authorized representatives of the
County to inspect and audit all data and reports of
the GRANTEE relating to its performance under the
Agreement.
D. GRANTEE shall provide the County, following completion
•
of the project, with an opinion from GRANTEE ' s
independent certified public accountant regarding the
transactions of the pro: ect.
VIII. TERMINATION OF AGREEMENT OR SUSPENSION OF PAYMENT
A. During the implementation of the Project, COUNTY may at
its sole option terminate this Agreement or may suspend
payment of Grant Funds to GRANTEE for GRANTEE' s
substantial breach of the Agreement, abandonment of the
Project or occurence rendering impossible the
performance by GRANTEE of this Agreement.
B. During the implementation of the Project, the COUNTY may
suspend payments of Grant Funds , when in the opinion of
the COUNTY, Grant Funds are used in a manner unrelated
to GRANTEE ' s performing the Project, the GRANTEE fails
to submit supporting information or documentation for a
claim, the GRANTEE submits incorrect or incomplete
reports , cr the GRANTEE suspends its pursuit of the
Prcf =c t .
C. In the event COUNTY elects to terminate this Agreement
or to suspend payments, for any reason stated
hereinabcve in paragraph A and 3 of this Section VII, it
shall notify the GRANTEE in writing of such action,
specifying the particular deficiency, and establishing a
time and a place for the GRANTEE to refute the alleged
deficiency at a time prior to COUNTY ' s taking such
action. After allowing the GRANTEE the opportunity to
refute or correct the alleged deficiency, if in the
opinion of the COUNTY, the alleged deficiency continues
to exist, the COUNTY may at its sole option withold
payment of the Grant Funds until such time as the
violation or breach is remedied or terminate this
Agreement. No action taken or withheld by the COUNTY
under this paragraph shall relieve the GRANTEE of its
liability to the COUNTY for any funds expended in
violation of any of the terms of this Agreement.
IX. REMEDIES
A. The Grantee shall defend, indemnify and save harmless
the County for any and all claims, litigation and
liability asserted against the County, its agents,
officers and employees and any costs and attorneys '
fees , on account of any and all injury including but not
limited to injury to and death of any person or persons
whomsoever, or on account of damage to any property
caused in any manner by the GRANTEE, their agents,
officers, employees or assigns arising from any and all
activity associated with or appurtenant to the Project.
The GRANTEE shall undertake said defense upon the
request of the COUNTY. In no event shall the COUNTY be
liable to the GRANTEE, its officers, agents, employees,
assigns, contractors and subcontractors for any claims
brought pursuant to this Agreement. The provisions of
this Paragraph shall survive the termination of this
Agreement by lapse of time or otherwise.
B. The GRANTEE convenants and agrees that it will not
suffer or permit any lien or claim to attach to the
funds of the COUNTY or to attach to the Grant funds by
reason of the Project . The GRANTEE shall save and keep
harmless the COUNTY and said funds from any lien or
claim therefore and from any and all costs and expenses
incurred by the COUNTY in connection with said liens or
claims .
C. In the event the GRANTEE shall in the opinion of the
COUNTY violate the terms and conditions of this
Agreement and the COUNTY at its sole option terminates
this Agreement, the GRANTEE shall within thirty (30)
days reimburse to the COUNTY, all Grant funds received
and shall make no claim for unpaid Grant Funds . Other
than those remedies specified in Section VIII, paragraph
C hereinabove, the GRANTEE shall have no other recourse
in a court of law or otherwise against the COUNTY.
X. TIMELINESS
A. Time is of the essence of this Agreement.
B. GRANTEE shall complete the Project, or the immediate
Project phase, within twelve (12) months from the date
of this Agreement.
C . If GRANTEE is delayed in the completion of the Project
by any cause legitimately beyond its control . it shall
immediately . upon receipt and knowledge of such delay .
give written notice to the COUNTY and request an
extension of time for completion of the Project. The
COUNTY shall - as soon as practicable . consider such an
Extension , act upon the extension request . and notify
the GRANTEE of the time extension granted or of its
denial of such request .
XI . MISCELLANEOUS PROVISIONS
A. AMENDMENTS - This Agreement constitutes the entire
Agreement between the parties hereto. Any proposed
change in this Agreement shall be submitted to the other
party for prior approval . No oral change or
modification shall be allowed and no claim therefore
shall be made . No modifications , additions , deletions .
or the like - to this Agreement shall be effective unless
and until such changes are executed in writing by the
authorized officers of each party .
B. ASSIGNMENT - except as provided in Section V hereof .
GRANTEE shall not assign this Agreement or any part
thereof and GRANTEE shall not transfer or assign any
Grant Funds or claims due or to become due hereunder .
without the written approval of the COUNTY having first
been obtained .
C. ATTORNEY ' s OPINION - If requested , GRANTEE shall provide
an opinion of its attorney . in a form reasonably
satisfactory to the Kane County State ' s Attorney ' s
Office - that all steps necessary to adopt this
Agreement . in a manner binding upon GRANTEE. have been
taken by GRANTEE. The GRANTEE shall provide the COUNTY
with a certified copy of the Resolution approving this
Agreement.
D. HEADINGS - The section headings of this Agreement are
for convenience and reference only and in no way define .
limit . or describe the scope or intent of this
Agreement . and should be ignored in construing or
interpreting this Agreement.
E. DISCLAIMER - Any report . study . advisory statement or
other such document produced by GRANTEE or consultant or
other person retained by GRANTEE , which is either an end
product or individual activity of Project. does not
necessarily reflect the policy . position or collective
thinking of the Kane County Government , the Kane County
Board or any officer or official agent of the same .
F. SEVERABILITY - If any section , clause . provision or
portion of this Agreement is judged unconstitutional or
invalid by a court of competent jurisdiction , the
remainder of this contract shall remain in force and not
affected by such judgement.
G. LANGUAGE DISPUTE - In the event a dispute arises
regarding the language of this Agreement, the original
copy of this Agreement in the possession of the County
of Kane shall control.
This Agreement shall be effective upon the signature of all
parties .
IN WITNESS WHEREOF, the parties hereto have executed this
Agreement on the dates recited below.
COUNTY OF KANE . a body politic in the
State of Illinois
By:
Chairman of the Board
DATE:
1, %,9
ATTEST:
County Clerk
GRANTEE: CITY 0 ELG
BY: /
Title
Date
ATTEST:
l _
City Clerk
EXHIBIT "A"
PROJECT OVERVIEW
SCOPE OF-WORK
The purpose of the activities funded pursuant to this Agreement
is to complete reiverfront redevelopment plans for the southeast
corner block at Illinois Rt. 31 and Kimball Street.
The scope of activities will be limited to the following :
1) Demolition and Environmental Remediation
2) Highway and Open Space Improvements
Payment pursuant to this Agreement is limited to not more than
50% of actual costs incurred for the above activities up to a
maximum KCCDAP cost of one hundred thousand dollars
($100 .000. 00) .
PROGRESS REPORT
The GRANTEE shall provide a Progress Report to the KCCDAP Office
quarterly. reporting on the status of the project in relation to
the Implementation Schedule. The progress reports shall begin
upon the signing of the Agreement -and shall continue until the
project is closed out.
OTHER REPORTING REQUIREMENTS
BID REQUIREMENTS
The Bid Specification, which will include all specifications and
pertinent attachments , shall define the items or services in
order for the bidder to properly respond . The GRANTEE may be
required to submit the bid specifications and plans to the KCCDAP
Office for staff 's approval prior to advertising. All bids will
be publicly opened at the time and place prescribed in the
invitation for bids .
The GRANTEE shall provide the KCCDAP office with the results from
the bid opening. Selection of bid for contract award shall be
conducted in accordance with prescribed procedures as set forth
in local . state or federal regulations .
REQUEST FOR PAYMENTS
Requests for payments shall be submitted on a timely basis. Each
request for payment sent to the COUNTY shall be accompanied by an
itemized list of activities covered under such payment to include
bills or invoices for services rendered or estimates for
activities where funding is necessary in advance.
IMPLEMENTATION SCHEDULE
GRANTEE will be responsible for meeting the schedule deadlines
shown below. Failure to meet this schedule may result in the
loss or reduction of Grant Funds .
MILESTONES DATE
1 . Demolition and Environmental 8/01/90
2. Highway and Open Space Improvements 10/01/91
COUNTY OF KANE
a�couNT
DEVELOPMENT DEPARTMENT o4` :`o,° County Government Center
•
719 Batavia Avenue
i{
Phillip S. Bus, Director ':s`. ..:'mss Geneva, Illinois 60134
• 471--����°• (708)232-3480
MEMORANDUM
August 10, 1990
TO: Eligible Applicants and Other Interested
Parties
FROM: Chris Aiston, KCCDAP Program Manager C;��v�'
RE: Fall, 1990 Funding Cycle
Please find enclosed a copy of the 1990 Kane County Community
Development Assistance Program (KCCDAP) Guidelines and Application.
Applications will be due October 1, 1990.
Mail Applications to:
KCCDAP
Kane County Development
719 S. Batavia Avenue
Geneva, Illinois 60134
On Wednesday, September 5, 1990 at 1: 00 P.M. , there will be held an
application workshop in the 3rd Floor Conference Room, Building A,
Kane county Government Center, 719 S. Batavia Ave. , Geneva, IL.
KCCDAP general objectives and specifics concerning application
preparation will be discussed.
Please RSVP to Ann Stark at (708) 232-3496 if your organization
will be represented at the workshop.
NOTE: Because of space limitations, organizations
Pwill be limited
to one representative.
_ ,_ 11
KANE COUNTY COMMUNITY DEVELOPMENT
ASSISTANCE PROGRAM
GUIDELINES AND APPLICATION
1990
�a-
OUTLINE OF KCCDAP GUIDELINES
Page
PART I Overview of KCCDAP 1
Part II Eligibility and Funding 3
.1 Eligible Applicants 3
.2 Eligible Activities 4
.1 Area Benefit Projects 4
.2 Housing Projects 4
.3 Consulting Services and Special Projects 6
.3 Miscellaneous issues 6
Part III Application and Project Selection Procedure 7
.1 Multiyear Funding Requests 7
.2 Application Instructions 7
.1 General Information 8
.2 Project Summary Form 9
.3 Project Description and Location Map 10
.4 Project Impact 11
.5 Project Financing 13
.6 Project Implementation 13
.7 Public Notice 14
.8 Environmental Impact Statement 14
.3 Applications & Project Selection process 15
.1 Submission of Project Applications 15
.2 Evaluation 15
Schematic of Approval Process 18
PART IV Administration and Project Management 19
.1 Grant Agreements and Amendments 19
.2 Acquisition Guidelines 19
.3 Contracts 20
.4 Process for Payment of KCCDAP Claims 21
APPENDICES
Appendix "A" , Application Form A-2
Appendix "B" , Project Ranking Criteria A-10
PART I
Overview of the Community Development Assistance Program
I.1 Kane County' s Recognition of the Importance of Public
Involvement in Community and Economic Development.
The Kane County Board has consistently supported efforts
toward community and economic development in Kane County. In
adopting and periodically updating an official Comprehensive Land
Use Plan and an Overall Economic Development Plan, the County
Board has publicly set forth certain goals and objectives
directly concerned with county-wide strategies for strengthening
the economic vitality of Kane County.
Both the Comprehensive Land Use Plan and the Overall Economic
Development Plan, however , enumerate a number of constraints
facing local governments in their attempt to implement community
and economic development strategies. At the forefront of these
constraints is the inability to obtain adequate funding to
construct new and expand existing infrastructure necessary for
development and redevelopment projects. There is also evidence
that comprehensive studies and marketing programs will be
required to insure future growth is managed properly and occurs
in a direction that is deemed most appropriate by the local
citizenry.
Kane County will experience substantial population and
employment growth in the coming years and therefore, constraints
and requirements such as those listed above will become
increasingly accute. The County Board recognizes the necessity
to plan for and properly manage the anticipated growth in Kane
County. It further recognizes that positive action must be taken
in order to create and implement sound strategies to manage
growth. Such action is best accomplished through
intergovernmental cooperation and it is for this reason that the
Kane County Board has established the Kane County Community
Development Assistance Program.
I.2 The Community Development Assistance Program.
The Kane County Community Development Assistance Program
(KCCDAP) was established by Kane County Board Resolution
No. 88-101 , adopted June 14 , 1988 .
The Kane County Community Develpment Assistance Program was
principally established to provide financial assistance to local
units of government in their efforts to create a favorable
climate for new community, commercial and industrial development.
The Kane County Community Development Assistance Program will
also provide funding to these agencies so that they may address
existing needs for improvement and redevelopment in these areas.
- 1 -
i
The Kane County CDAP differs substantively from financial
assistance programs offered by the state and federal governments
in the area of funding itself. Whereas the State of Illinois'
Community Development Assistance Program and the U.S. Department
of Housing and Urban Developments' Community Development Block
Grant Program are wholly funded through tax dollars, the Kane
County Community Development Assistance Program is being
supported annually through a grant from the Kane County
Enterprise Fund. Also, unlike the federal and state grant
programs which require a variable local commitment of funds as a
percentage of the total project budget, the KCCDAP requires .a
straight dollar for dollar cash match for` all eligible projects
and activities.
The County' s Enterprise Fund was established from revenue
generated by landfills sited within Kane County. The grant
funding the KCCDAP is based on an amount equal to $0 .15 per cubic
yard of waste deposited in said landfills. In essence then, the
County KCCDAP program is funded from user fees and therefore
signifies an opportunity for the citizens of Kane County to get a
monetary return on their waste disposal costs.
- 2 -
PART II
ELIGIBILITY AND FUNDING
II.1 Eligible Applicants
II 1 .1 General
Only units of local government and closely affiliated
organizations may apply for Kane County CDAP funds. This list
includes but is not limited to the following: County Board,
County Forest Preserve District , cities, villages, townships,
school , park and sanitary districts , economic development
commissions and chambers of commerce.
II 1 .2 Sponsorship or "On Behalf of" Applications
General units of local government may also submit "on behalf
of" applications for local entities that otherwise may not be
eligible to apply. Examples of a local entity which may receive
funding through an application of this type are non-profit groups
and neighborhood based non-profit groups. A neighborhood based
non-profit group:
a. Must be duly organized to undertake community
development activities within a neighborhood; and,
b. Is considered neighborhood based if a majority of its
membership, clientele, or governing body are residents
of the neighborhood where the project will be located.
Further, a neighborhood is defined as a geographic location
within a jurisdiction of a unit of local government (but not the
entire jurisdiction) designated in comprehensive plans,
ordinances, or other local documents as a neighborhood. An
entire jurisdiction of a unit of general local government may be
considered as a neighborhood if its population is less than 1 ,000
persons.
II 1 .3 Multi-Jurisdiction or Joint Venture Projects.
In a situation where two or more eligible local governments
face a common problem, a joint application may be filed. Local
governments, however, must not only share a common problem but
must be able to demonstrate that a joint effort is required to
solve the problem. Joint applications which are submitted only
for administrative convenience will not be accepted. Generally,
the county will look with favor on joint applications, which are
otherwise valid, as such applications encourage intergovernmental
planning and cooperation.
II 1 .4 Multi-cycle Projects and Project Planning.
Kane County will accept KCCDAP applications for projects
requiring multi-cycle funding. Projects necessitating this type
of request include those requiring large sums of money and/or
those which naturally are best phased and thus timed so to be
consistant with development needs. By breaking down large
- 3 -
}
projects in phases or milestones and requesting funds over a
period of time, the applicant may better able itself to ensure
timely completion of each phase and further show proof that it
can complete KCCDAP expenditures within one year of receiving
them.
II 2 . Eligible Activities
The Kane County Community Development Assistance Program
offers matching grants for three categories of project
activities. The following is a general discussion of these three
categories.
II 2 .1 Area Benefit Projects.
Area benefit projects are generally discribed as those that
create, expand or improve public facilities. Examples of area
benefit projects are listed below.
1 . Provision of public utilities
2 . Drainage improvements and other stormwater management
projects
3 . Construction or improvements to roads, streets,
sidewalks and bridges
4 . Waste management planning and/or projects
5 . Development of park land
6 . Construction or improvement of public buildings
7 . Aquisition, demolition, property clearance, or site
improvements for the above
8 . Removal of architectural barriers in public areas
II.2 .2 Housing Projects.
The primary criterion for defining a housing project is that
it must create new permanent or temporary housing opportunities,
rehabilitate existing housing, or improve the effectiveness of
existing housing in an effort to prevent or eliminate blight.
The project may be defined as one that creates new permanent or
temporary housing opportunities if (a) it results in newly
constructed housing (b) non-residential structures are converted
to housing or (c) existing housing prior to rehabilitation was
considered substandard but will be brought up to current building
code following rehabilitation. Rehabilitation activities may
include repair of public or privately owned housing and may be
undertaken to improve single family as well as multiple family
housing.
Listed below are examples of the type of projects eligible
for funding.
1 . Acquisition and disposition of property for housing
purposes (this may be vacant land and/or existing
structures)
2 . Rehabilitation of existing housing (single or multiple
family)
3 . Conversion of non-residential structures to residential
- 4 -
4 . Removal of architectural barriers in residential
facilities
Ineligible uses of KCCDAP funds for housing include direct
financial assistance to individuals for payment of rent , or
purchase of a home or home improvements.
II. 2 .2 .1 Projects Located in a Blighted Area.
To be determined as a blighted area, the following two
conditions must be present.
1 . The area must have a substantial number of deteriorating
or dilapidated structures.
2 . The area must meet the definition given below of a
blighted area.
Blighted areas are defined as :
Any area of not less in the aggregate than two (2) acres
where buildings or improvements, by reason of dilapidation,
obsolescence, overcrowding, faulty arrangement or design,
lack of ventilatiion, light and sanitary facilities,
excessive land coverage, deleterious land use or layout or
any combination of these factors, are detrimental to the
public safety, health, morals or welfare.
Documentation that the benefited area meets the above
definition is required as part of the project applicaton,
including a map outlining the blighted area. It is also
recommended that the blighted area be officially so designated by
the governing body with jurisdiction over the area.
The second part of the standard for a blighted area is that a
substantial number of deteriorating or dilapidated structures
must exist throughout the area. The term "substantial number" is
not precisely defined. However, this number must be viewed in
relation to all structures in the designated blighted area. At a
minimum, thirty percent of the structures in the area should show
evidence that basic structural elements (foundations, walls,
etc. ) are suffering from significant deterioration.
Location of a project in a blighted area is not sufficient to
show that the project addresses a factor that is causing the
deteriorated condition in the area. The applicant must show that
the activity is designed to address one or more of the conditions
that qualify the area as blighted. For example, if the project
is designed to reduce flooding in the blighted area, the
applicant must show that flooding is a major cause of the
blighting conditions in the area.
II. 2 .2 .2 Activities Located Outside a Blighted Area.
KCCDAP will fund acquisition, demolition, rehabilitation,
relocation, and historic preservation activities designed to
eliminate specific conditions of blight or physical decay on a
spot basis not located in a blighted area. These kinds of
- 5 -
activities are considered as consistent with the County' s overall
economic development program. However, under this standard,
rehabilitation is limited to the extent necessary to eliminate
specific conditions detrimental to public health and safety.
This provision is primarily designed to allow for rehabilitation
programs that by their nature, address substandard conditions on
a scattered basis throughout the applicant' s jurisdiction.
Documentation for this type of project must include (a) a
description of the specific conditions of blight that the project
will be addressing and (b) a discussion of how the project will
address these conditions.
II.2 .3 Consulting Services and Special Projects.
Contracting for consulting services and special projects are
eligible activities for KCCDAP funding. These services and
projects are typically associated with activities having
community wide benefits. Examples of activities which may be
eligible within this category are as follows:
A. Riverfront Improvement
B. Community Beautification
C. Professional Studies or Reports
D. Comprehensive Plans, Zoning Ordinances, etc.
E. Other Engineering or Feasibility Studies
F. Preparation and Printing of Informational/Promotional
Materials
G. Other Projects Designed to Stimulate Local or Regional
Community or Economic Development
II.3 Miscellaneous Eligibility Issues
The applicant should be aware of several other eligibility
considerations that must be checked before a final determination
of project eligibility can be made. Failure to meet regulations
and guidelines regarding any one of the following issues could
make a project ineligible for KCCDAP funding.
Environmental Concerns
Aquisition Guidelines
Contract Requirements
These guidelines are reserved in Section IV in this Handbook.
KCCDAP funding may not be provided for projects where these
guidelines are applicable, and work has already progressed to the
point where compliance cannot be assured. Any applicant that has
already advertised or negotiated a construction or purchase
contract , or in any way has begun the process of acquisition
prior to submitting an application should contact the County
Development Department for advice regarding the eligibility of
the proposed activity.
- 6 -
PART III
Application and Project
Selection Procedure
The application and project ranking criteria for the KCCDAP
Program are discussed in detail in this section and Appendices A
and B. Applicants are encouraged to read these two sections
carefully to ensure that their application has been properly
filled out.
III.1 Multi-cycle Funding Requests
Many projects, particularly those involving large scale
public improvements or a variety of components, may be better
planned and funded over time. Recognizing this fact , KCCDAP
grants can be distributed for a single project over a multi-cycle
period. In most cases, these funding cycles will follow one
another at each six month interval. In some cases, however,
funding will be requested and distributed on a one cycle per year
basis. In either case, no grant award commitment will exceed
three cycle dispersals and/or $150 ,000 .00 in KCCDAP grant monies.
The application form has been designed for both single cycle
and multi-cycle projects. For multi-cycle projects, the
following information is required:
1 . The funding requested (Item 1 .6) will only cover the
current one-cycle period. However, the applicant must
show that multi-cycle funding is requested and indicate
which cycle is to be funded by the current request.
2 . Separate Project Summary Forms are required for each
- cycle' s activities. This includes future cycles as well
as any previous cycle' s activities.
3 . Section 3 of the application should describe the
complete multi-cycle project. However , the description
of the current cycle' s activities should be the most
detailed.
4 . The information provided in Sections 4 , 5 and 8 of the
application should cover the complete multi-cycle
project.
5 . The implementation schedule in Section 6 must cover all
phases of the project. However , implementation of the
current cycle' s activities should be described in the
greatest detail .
6 . Only one public notice (described in Section 7) is
required for a multi-cycle project. The notice must
make it clear that the applicant is requesting funding
for more than one cycle.
III.2 Application Instructions
The applicant should limit the description of the project to
the application form itself. Additional information may be
attached, but no information in a format larger than 8 1/2 inches
by 11 inches should be submitted.
. - 7 -
ti
The discussion below describes, in detail , how to complete
this form.
III.2 .1 General Information About The Project
2 .1 .1 Name of Applicant: The name provided should be the
agency that will be the actual recipient of the grant
funds. A representative of the agency may be called
upon to give the presentation of the project to the
Development Committee, and if funded, this
representative should be the person responsible for the
project ' s completion.
2 .1 .2 Name of Project: This is self explanatory.
2 .1 .3 Type of Application: All applications submitted during
the regular round of funding will be considered
originals. A revised application will be indicated if
the application is resubmitted with changes prior to
final County Board approval of the Grantee Agreement for
the project. If the project changes after County Board
approval of the agreement, it will be necessary to
submit an amended application.
2 .1 .4 Contact Person: This person should be the individual
responsible for the application, and if possible, the
individual who will also have on-going responsibility
for the project.
2 .1 .5 Project Abstract: In the space provided, describe the
project (i.e. what the KCCDAP funds will be used for) in
a summary fashion. This is not meant to be a complete
and detailed description of the project, but enough
information should be included to provide a basic
overview of proposed activities. Please limit this
abstract to the space provided. Do not describe your
organization and what it does.
2 .1 .6 KCCDAP Funding Requested: List the total amount of
KCCDAP funding requested for the current round of
funding. This figure will be the same as the total for
column 2 .5 of the "Project Summary Form". If the
funding request for the current cycle is part of a
multi-cycle project, the applicant should indicate which
cycle will be funded by the current request.
2 .1 .7 Project sponsor: County Board policy requires that all
applications for CDAP funding be either submitted or
sponsored by a Kane County local governmental or quasi-
governmental agency as described in Section I.1 . Any
organization that cannot submit an application directly
must arrange for such an agency to sponsor the
application, and written evidence of this endorsement
must be supplied to the County Board. The applicant
should make every effort to obtain the most appropriate
sponsor depending on the location and the type of
project for which KCCDAP funds are being requested.
- 8 -
2 .1 .8 Certification: The person who signs the application
must be authorized to sign for the applicant.
III.2 .2 Project Summary Form
Descriptions of the separate activities included in the
project should be as brief as possible, but may include
-additional pages of this form if the project is made up of
several separate activities.
2 .2 .1 Project Phasing: For multi-cycle projects, indicate
which cycle' s activities are described on the form.
Separate Project Summary Forms must be submitted for
each cycle' s request (including previous cycles, whether
or not activities were funded by KCCDAP) . If the
applicant is applying only for a single-cycle project,
this item should be left blank.
2 .2 .2 Activity and Location: All activities included in the
project must be listed in this part of the form whether
or not the specific activity will be funded with KCCDAP
funds. Information provided should be brief since a
more detailed description of activities will appear in
3 .1 of the application. Many projects will be made up
of several activities, and each should be listed
separately. The following list includes recommended
categories of activities.
A. Acquisition of real property
B. Disposition
C. Public works and facilities (List separately each
specific type carried out, e.g, senior center,
streets, sewers, etc. Engineering or architectural
activities for these facilities should also be
listed as separate activities under this category. )
D. Clearance
E. Public services (If more than one is included in
the project , list each separately. )
F. Relocation of persons, households, or businesses
displaced by KCCDAP funded actions, if any
G. Removal of architectural barriers
H. Rehabilitation (List separately each activity using
the appropriate title below. )
- Single family residential
- Multi-family residential
- Public housing modernization
- Other publicly-owned non-residential
- Publicly-owned non-residential
- Historic preservation
- Renovation of closed schools
- Energy efficiency improvements (only if used
exclusively for this purpose; otherwise
include in one of the categories above)
- 9 -
I. Commercial or industrial improvements by a grantee
or non-profit group
J. Special activities by subrecipients
K. Planning (List specific activities)
Location information is also required for each of the above
activities, and should be provided according to the following
categories.
A. Parcel number (s) if applicable
B. Street address - If the project is such that
the location can be specifically described by
street address, this information should be
provided. This also applies to projects such
as sewer or water lines where an address range
should be provided (e.g. , McKee Street from
Western to Randall) .
C. City or countywide - In some cases the project
may not have a specific location.
2 .2 .3 Funding Category: This column refers to the funding
categories of area benefit, housing, or consulting
services and special studies. Indicate from which one
of these three categories the activity will be funded.
2 .2 .4 Non-KCCDAP Funding Amount: Any funds other than KCCDAP
dollars that will be going toward the project must be
shown in this column. This information must include all
other sources of funding including local share, other
grants, donations, private sector funds, etc. A more
specific description of these funds will be provided in
item 5 of the application.
2 .2 .5 KCCDAP Funding Amount: The requested amount of KCCDAP
funding for each activity appears in this column.
2 .2 .6 Total Costs: The total cost for each activity should be
listed in this column.
Finally, the applicant should sum each of the three cost
columns to provide the totals at the bottom of the
Project Summary Form.
III.2 .3 Proiect Description and Location Map.
2 .3 .1 Proiect Description and Specifications: This
description should include : (a) a general description
of each activity; (b) a summary of project
specifications, such as lineal feet of line installed,
housing units created or rehabbed, etc. ; and (c)
estimated number of persons to be benefited. Although
the description should be comprehensive, space is
provided elsewhere to discuss needs, benefits, financing
and project scheduling. Therefore it is not necessary
to elaborate on these components. If the project
requires multi-cycle funding, this description should
cover the entire project, but- it should provide greater
detail for the current cycle.
- 10 -
•
2 .3 .2 Location Map Included: Indicate whether a location map
is included with the application. Any project that is
benefiting a specific area must include a map that
delineates the boundaries of the area benefited. If the
project is addressing the prevention or elimination of
blight, the designated blighted area must be shown.
III.2 .4 Project Impact
The information provided in this section of this application
form is of critical importance. All data provided should also
include the source of these data. Provide information for each
separate activity as follows.
A. Water and Sanitary Sewer
- Provide data on the total area and number of
dwelling units benefited by the project.
- Indicate the number of households where there
is specific evidence of a health or safety
hazard resulting from the inadequacy of water
and/or sewer facilities.
- Describe any direct emphasis the project will
have on historic preservation, environmental
protection, or energy conservation.
B. Drainage or Flood Management Projects
- Provide data on the total area and number of
dwelling units benefited by the project.
- Indicate how many dwelling units in the
benefited area are currently being flooded at
least once a year to the extent that it causes
significant damage to the structure of the
unit.
- Indicate the extent of yard and street
flooding (frequency and severity) , and number
of units affected by this type of flooding.
- Describe any direct emphasis the project will
have on historic preservation, environmental
protection, or energy conservation.
C. Street Improvements, Bridges , Sidewalks, and Street
Lighting.
- Describe the specific area to be benefited by
the new or improved streets, bridges,
sidewalks or lighting.
- If the project improves existing facilities,
describe the current condition of the present
facilities.
- Provide specfic data indicating any safety
hazards that currently exist due to the
condition or inadequacy or the current
streets, bridges , sidewalks, and street
lighting.
- 11 -
- Describe any direct emphasis the project will
have on fair housing, historic preservation,
environmental protection, or energy
conservation.
D. Waste Management Planning/Projects
- Indicate total number of housing units,
commercial or industrial facilities,
institutions, etc. which will be affected or
are a part of the service area.
- Provide data indicating the existing problem
related to the project' s objective and how the
proposed project will help to alleviate the
same.
- Describe any direct emphasis the project will
have on fair housing, historic preservation,
environmental protection, or energy
conservation.
E. Housing Projects/Activities
- Indicate the total number of housing units to
be created or rehabilitated; or the number of
households or clients that will be served or
assisted.
- Indicate the number or percent of the above
units or services that will be used by the
elderly or handicapped.
- Provide information demonstrating the need for
the type of housing or housing program
proposed. Acceptable documentation may
include market analysis, need surveys, or the
past experience of the project/program or of
similar activities.
- Describe any direct emphasis the project will
have on fair housing, historic preservation,
environmental protection, or energy
conservation.
F. Open Space/Recreation
- Describe the current condition or availability
of open space/recreation facilities for the
area to be served. In particular, the
applicant should indicate the location of the
nearest recreation facilities similar to the
facility proposed.
- Provide data on the total area to be served by
the new or improved facilities including the
average residential density in the area.
- Describe any direct emphasis the project will
have on historic preservation, environmental
protection, or energy conservation.
- 12 -
G. Handicapped Accessibility Improvements
- If the users of an accessible facility are to
be the general public, you need not provide
additional data on need. However, if the
facility will be used by a limited number of
persons or a special clientele, provide
specific data showing the percent of the users
of the accessible facility that would be
handicapped.
- Describe any direct emphsis the project will
have on historic preservation, environmental
protection, or energy conservation.
H. Planning, Engineering, Feasibility Studies, Etc.
- Information about the general need for the
study should be provided.
III.2 .5 Proiect Financing
Provide specific information concerning the source and amount
of any non-KCCDAP funds used to finance the project.
III.2 .6 Project Implementation.
2 .6 .1 Where applicable, the following imformation must be
provided.
A. The status of preliminary and final project
planning must be described. This includes
engineering, architectural drawings, or any other
preparatory work necessary to begin the project.
B. If a specific site is required for the project, the
applicant must describe its ownership status over
the project site.
- Are the required parcels owned by the
applicant or otherwise immediately available?
- What parcels or easements need to be acquired?
- Are there any reasons, known to the applicant,
why these parcels or easements would be
difficult to acquire (such as an unclear
title, the need to relocate tenants or
homeowners, or environmental conerns) ?
C. If acquisition of property is required, but the
applicant is flexible as to the specific property,
the applicant must provide information on the
availability of suitable properties and possible
zoning issues or neighborhood concerns that might
arise regarding the proposed use.
2 .6 .2 Implementation Schedule: The applicant should assume
that funds will be available during the month of
June/December (However, this would not preclude any
project from starting earlier if special arrangements
13 -
rr
have been made with the County Board or its designee. ) A
completion date must be supplied for each milestone
applicable to the project. Milestone "a" is required
for all projects except planning and consulting
services, and must be completed before other activities.
If the applicant has any questions about the
applicability of specific milestones, the County
Development Department office should be contacted.
•
III.2 .7 Public Notice.
A public notice specific to each application is required.
Agencies submitting more than one application may combine the
separate projects into one notice. However, it should be made
clear to the public that separate applications will be filed. If
a project will affect non-English speaking or reading residents,
the applicant must publish the notice in the predominate foreign
language.
Legal notice must be published at least 10 days prior to the
date the application is due at the County Development Department
so that persons, governments, and other groups affected by the
project are made aware of the proposed project and have an
opportunity to comment in writing. The notice must inform
citizens (1) what the proposed use of funds will be; (2) what
areas will be affected; (3) expected duration of time; (4) that
written comments will be accepted; and (5) whether the project
will result in the displacement of residential or business
tenants.
2 .7 .1 Publication Date: Indicate the date notice was
published. (Attach certification)
2 .7 .2 Public Comments and Response: Applicant shall accept
public response and comments before and for a minimum of
15 days after the application due date. Summarize any
written comments received. Any letters of support
attached to the application should also be listed here.
If you feel that a response is necessary to any public
comment received, you should include it in this section.
Copies of all written comments should be forwarded to
the County Development Department, Attn: RCCDAP. If no
comments were received, this should be stated here.
III.2 .8 Statement of Environmental Impact
All projects require the completion of a Statement of
Environmental Impact (SEI) . No commitment or expenditure of
funds will be made on the project until the SEI has been received
and reviewed by the Development Department Staff.
The Statement of Environmental Impact should be a brief , yet
comprehensive assessment of the project' s immediate and long term
impacts on the subject area' s physical and social environment.
At a minimal , the "Statement" must address, if applicable, each
of the following issues:
- 14 -
•
1 . Conformance with floodplain/wetland management
regulations
2 . Protection of wildlife habitats
3 . Impact of natural or man-made hazards
4 . Affect of and impact on soils
5 . Impact on groundwater supplies
6. Historic preservation
7 . Air quality
8 . Conformance with local and regional plans
9 . Impact on social and neighborhood quality
III.3 Submission of Applications and Project Selection Process
A flow chart outlining the process for project selection
appears in this Section on page .
III.3 .1 Submission of Project Applications
The applicant should be aware of several steps in the process
that take place before applications are due. First, the
Development Committee will determine the total amount of funds to
be available.
Second, grant guidelines and application packets will be
mailed to all known potential applicants. This will take place
approximately thirty days before applications will become due.
Applicants will be told the actual date applications will be due.
Applicants are encouraged to call or write to KCCDAP Contact with
any questions or concerns before the application due date.
Third, each applicant is required to publish a legal notice
specific to the project or projects that are sponsored by that
applicant. Section III.2 .7 of this handbook should be reviewed
for information regarding this requirement.
Finally, applications (including one original and 7 copies)
will be due in the Kane County Development Department office. •
The due date will be clearly stated in the application packet.
Supplemental information such as public comments and letters of
endorsement may be submitted after this date.
III.3 .2 Evaluation
3 .2 .1 Staff Evaluation.
Staff evaluation will begin by reviewing the application for
completeness. If the applicant has omitted any part of the
required documentation, they will be notified as soon as possible
so that the additional information can be supplied for continued
staff evaluation.
The application will be evaluated for the basic eligibility
of the proposed activity and for compliance with the stated goals
and objectives in current county and/or municipal economic
development, growth management and comprehensive land use plans.
- 15 -
' t
All projects that are determined eligible will be further
evaluated based on project ranking criteria and a point system as
adopted herein and shown in Appendix B.
Generally, the system awards points to projects based on
community development objectives that will be achieved by the
project. A maximum of 20 points in each of three categories may
be awarded for a total possible of 60 points. These three
categories are as follows:
A) Conformance with county and/or municipal plans
B) Project Impact
C) Project Readiness and Applicant' s Past Performance (if
any)
For projects that have a specific proposed location, staff
may visit the site during its evaluation of the project. A
representative of the applicant may be required to attend this
site visit. The applicant will also be informed of the results
of staff evaluation and will be invited to discuss it prior to it
being submitted to a Development Committee.
3 .2 .2 Development Committee Evaluation.
Each applicant will be given the opportunity to present basic
facts about its application to the committee. However, this
presentation is optional. Staff will contact all applicants to
arrange a schedule of presentations.
Although the ranking criteria form the basis of the selection
process, the Development Committee may take three additional
actions before it develops its recomendation. First, the
Committee may change the number of points tenatively awarded to
some projects for meeting specific criteria. Some of the
criteria require the judgment of staff in order to award points,
and after presentations and Committee reviews, they may feel that
some of the components of certain project evaluations should be
reconsidered. Second, the Committee may establish a minimum
point cut-off and not award all funds presently available. In
this case , it will probably recommend that the unused funds be
transferred to a later funding cycle. Third, the Committee may
negotiate with specific applicants to reduce their funding
request so that more projects can be funded.
III.3 .3 Final Approval and Grant Award
3 .3 .1 Final Approval.
When the above steps have been completed, the Development
Committee will develop a final recomendation. This
recommendation will be submitted to the Kane County Board for
final action. The action by the County Board will include the
final list of projects for the present KCCDAP funding cycle.
3 .3 .2 . Change to Final List of Projects Awarded KCCDAP Funding
- 16 -
The final list as approved by the Kane County Board may be
changed as a result of the following:
A. Grantee withdraws, in writing, its request for grant
funds;
B. The proposed project becomes altered in its scope of
activities between grant award and contract execution
such that, in the County' s judgement, the project can no
longer be funded during the present funding cycle; or
C. An event or events occurring which makes compliance with
these guidelines and the grant award contract
impossible.
No amendatory list need be adopted by the County Board after
a change to the final list has been made and any funds no longer
committed as a result of said change will be either made
available to an applicant or applicants not previously awarded a
grant or grants, or transferred to a later funding cycle budget.
- 17 -
FLOW CHART FOR KCCDAP PROJECT APPROVAL
STAFF/APPLICANT ACTIVITIES DEVELOPMENT COMMITTEE ACTIONS COUNTY BOARD ACTIONS
APPROVE ANNUAL BUDGET
ESTABLISH CYCLE BUDGET
NOTIFY APPLICANTS (S)
PREPARE APPLICATIONS (A)
PUBLISH PUBLIC NOTICE (A)
SUBMIT APPLICATIONS
BEFORE 10/1/90 (A)
PROJECT EVALUATION (S/A)
°o REVIEW STAFF EVALUATIONS
• PRESENTATION TO DEVEL.
COMMITTEE (OPTIONAL) (A)
RECOMMEND GRANT AWARDS
ADOPT RESOLUTION
APPROVING GRANTS
ENTER INTO AGREEMENT WITH
KANE COUNTY BOARD (A)
PROJECT BEGINS -
PART IV
AND
ADMINISTRATIONPROJECT MANAGEMENT
IV.1 Grant Agreements and Amendments
Agreements between the grantee and the County Board are
required for all projects not undertaken by the County itself.
For each affected project, this Agreement must be executed by an
offical action by the grantee and the County Board, and the
Agreement must be in effect prior to the commitment or
expenditure of funds for any activity included in the project.
Projects undertaken by the County will be subject to a Memorandum
of Understanding between the County and the appropriate
department head.
If the applicant requires a sponsor, a Grantee Agreement will
be executed between the County and the sponsor. It is suggested
that the sponsor execute an agreement similar in form to the
Grant Agreement between itself and the sponsored agency.
Applicants sponsored by the County will enter into a standard
Agreement directly with the County.
Whether an Agreement or a Memorandum of Understanding is
used, the form and language are very much the same. Generally,
the Agreement includes:
1 . A detailed description of the scope of activities paid
for with KCCDAP funds;
2 . The total KCCDAP funding allocated to the project;
3 . A specific time schedule for project completion;
4 . A description of reporting requirements and local
regulations applicable to the project; and
5 . A description of the remedies for non-compliance with
terms and conditions of the agreement.
Amendments to Grant Agreements may be considered to extend
the time period covered by the Agreement, alter the amount of
KCCDAP funding allocated to the project , and/or change the scope
of activities funded by KCCDAP funds. The Grantee must request
the amendment in writing and provide adequate documentation of
the need for the amendment. All amendments must be officially
executed by the Grantee and the County Board.
If the project required a sponsor , the Grantee must notify
the sponsor of the requested amendment giving them adequate time
to comment on the request (keeping in mind that it will actually
be the sponsor that will be adopting the amended Grant Agreement
with the County) .
IV.2 Acquisition Guidelines.
All KCCDAP funded projects in which it is necessary to
acquire real property, regardless if KCCDAP or non-KCCDAP funds
are used, will be subject to the guidelines given below. Any
acquisition activities must be included in the cost and
scheduling information that appear in the application.
- 19 -
.
:J
IV.2 .1 The Acquisition Process
2 .1 .1 Negotiation to Purchase Using Eminent Domiain
This procedure can only be used by a Grantee that has been
granted eminent domain powers by law. Rules and procedures
concerning eminent domain are set forth in Illinois Revised
Statutes, as amended, and are applicable for all KCCDAP projects.
2 .1 .2 Voluntary Acquisition.
Whenever and where ever possible, the process of voluntary
aquisition should be used. The voluntary acquisition process is
often quicker and less expensive than the process of eminent
domain. The Grantee must (a) advertise in the project area to
see if any property owners are interested in selling to them or
(b) purchase property that is currently listed ✓for sale.
2 .1 .3 Dedication/Donation of Property.
Nothing in the regulations prohibits an owner from donating
property, if prior to the donation:
1 . The Grantee informs the owner, in writing, as to the
amount established as just compensation for the
property; and,
2 . The owner indicates in writing that he/she understands
that he/she cannot be required to donate or sell the
property to the Subgrantee at less than the amount
determined to be just compensation, but he/she
voluntarily agrees to do so.
In cases requiring acquisition, the applicant is encouraged
to contact the Development Department office when putting
together the application in order to account for likely costs of
this acquisition. If the project is funded, it is critical that
the Grantee maintain close coordination with the Development
Department office during the acquisition process.
IV.3 Contracts
IV.3 .1 General Requirements
KCCDAP-funded activities require that an outside agency or
firm be contracted to complete all or part of the work. The
Grantee will be responsible for assembling the bid documents or
request for proposal and local laws and regulations relative to
public notice and bid opening are applicable.
IV.3 .2 Equal Opportunity.
All contracts and subcontracts must contain the following
equal opportunity clause:
The Contractor shall not discriminate against any
employee or applicant for employment because of race,
color, religion, sex, or national origin.
- 20 -
e
;1.
Further, all contracts and subcontracts shall require this clause
be posted in some form on the job site and that it is made known
to job applicants.
IV.4 The Process for Payment of KCCDAP Claims.
There are different types of claims which are discussed
below, but all payments are subject to three policies: 1) all
checks distributed for payment of KCCDAP claims must be
authorized by the County Board; 2) disbursement of KCCDAP funds
Grantees must take place no later than ten (10) days after the
receipt of the check for payment; 3) KCCDAP funds cannot be
deposited in an interest-bearing account prior to disbursement.
IV. 4 .1 Types of Claims and Required Documentation.
The most common type of claim received from Grantees is a
payment pursuant to a contract. Documentation for claims on
construction contracts must include an itemization of work
completed with a separate cost for each item. Invoices for all
materials are also required. Final payment on construction
contracts cannot be paid until the Development Department Staff
(a) receives certification that work is complete as per
specifications, (b) receives a waiver of all liens against the
contractor for work done on the project , and (c) has cleared
required contract provisions. For consultant contracts, the
final claim will not be paid before receipt of a copy of the
product developed by the consultant.
The Grantee has the option of (a) paying the contractor and
requesting reimbursement for KCCDAP program funds or (b) timing
the request for payment such that the Grantee can pay the
contractor directly upon receiving the County check. The option
chosen will depend on the cash flow situation of the Grantee
and/or the terms of the agreement with the contractor .
Another type of claim involves the acquisition of real
property. Because of the large amounts usually involved, these
claims often cannot be paid on a reimbursement basis. In
addition, it is necessary that funds be available on a specific
closing date. Required documentation includes a copy of the
purchase contract and an estimated pre-closing statement of total
expenses. Timing of the Grantee' s claim and documentation is
very important for these projects, and the Development Department
office should be notified of the closing date as early as
possible.
IV.4 .2 Claims
All claims must be submitted on a Payment Request form
supplied by the County and must be accompanied by an additional
form, also furnished by the County, wherein all general
activities listed on the Payment Request form are further
explained through an itemized breakdown of costs, where
applicable. Copies of relevant documentation (invoices,
contracts, etc. ) shall be attached. Requests for funds as
reimbursement for completed activities must be accompanied by a
- 21
J
cancelled check or a copy of a check showing actual payment was
made. Any claim will be for no more than half the amount of the
check.
IV.4.3 . Receipt of Claim and Documentation
The claim as well as the appropriate documentation must be
submitted directly to the KCCDAP office, Kane County Development
Department. For real property acquisition, the Grantee should
also submit a pre-closing statement for KCCDAP review.
- 22 -
c ,
APPENDICES
A-1
H .
APPENDIX A
APPLICATION FORM
KANE COUNTY CDAP
GENERAL INFORMATION ABOUT THE PROJECT
1. 1 Name of Applicant
1. 2 Name of Project
1. 3 Original Revision Amendment
(Date) (Date)
1. 4 Contact Person:
Name and Title
Address Phone
City Zip Code
1. 5 Project Abstract (Below - Provide a brief description of
the project)
i
1. 6 KCCDAP Funding Requested:
For Multi-Cycle Project: The funding requested is for
Cycle of a Cycle Project
1. 7 List Project Sponsor (If applicable, See Sect. II . 1 . 2) :
*Attach a Letter or Resolution of Endorsement
1. 8 CERTIFICATION: To the best of my knowledge and belief, data
in this application are true and correct, the document has
been duly authorized by the governing body of the applicant,
and the applicant will comply with all regulations and guide-
lines applicable to Kane County' Community Development
Assistance Program.
Signature Date
A-2
2. I'IU),JECT SUMMARY FORM Page of
2.1. Project Phasing: Cycle_ of _
(Submit additional copies of this form estimating
costs of future phases)
2.11. Non-KCCDAP 2.5. KCCDAP
2.3. Funding Funding Funding 2.6. Total
2.2. Activitiy and Location Category Amount Amount Cost
w
TOTAL
3 . PROJECT DESCRIPTION AND LOCATION MAP
3 . 1 Project Description and Specifications:
3 . 2 Location Map Included: Yes No
A-4
r
4 , PROJECT IMPACT
1
A-5
5. PROJECT FINANCING
Provide information about source and amount of any non-KCCDAP
funds used to finance the project (be as specific as possible) .
•
A-6
6 . PROJECT IMPLEMENTATION
6 .1 Project Readiness:
15 6 .2 Implementation Schedule:
Milestone Completion Date
a.
B.
C.
D.
E.
F.
G.
A-7
S '
7 .PUBLIC NOTICE
7 . 1 Publication Date:
*Attach certification
7 . 2 Comments and Responses:
A-8
8. ENVIRONMENTAL IMPACT STATEMENT
(See Section 111.2 .8 . of Guidelines)
A-9
APPENDIX B
PROJECT RANKING CRITERIA
For projects that are determined as eligible, points will be
assigned by the Kane County Development Department Staff based on
the system described below. The Development Committee' s will
then review the projects and the staff' s point assignment and
recommend modifications of points assigned for specific
components where appropriate. Applicants will also have the
opportunity to meet with the Committee to discuss their project.
The point system allows for a maximum of 20 points in each of
three categories for a total possible of 60 points. The three
categories are as follows:
1 . Conformance with county and/or municipal plans.
2 . Project Impact.
3 . Project Readiness and Applicant' s Past Performance.
The specific point system is described below including the
rationale behind the assignment scores.
POINT CATEGORY ONE: CONFORMANCE WITH COUNTY AND/OR MUNICIPAL
PLANS
The Kane County Comprehensive Lane Use Plan and the Kane County
Overall Economic Development Program and Plan have listed several
goals and objectives relative to economic development and sound
management of population and employment growth. There are also a
number of Kane County communities which have adopted plans
wherein these issues are addressed in detail .
In order for the applicant to receive a high score in this
category, it must show that the proposed project conforms with
either regional or local plans, or both. Dual conformance,
coupled with a showing of positive impact on surrounding areas,
will generally result in a high score in this category.
If an applicant submits a project for funding which has no basis
in either the county' s plans or those plans publicly set forth by
any local government affected, but can make a valid argument that
the purpose of the project is in line with local or regional
goals and objectives, the project will receive a moderate score
in this category. If no such argument is made, the points
assigned will be variably minimal.
If a proposed project is deemed counterproductive relative to the
county' s plan or a plan of an afected local public agency, then
the applicant may receive no points for Point Category One.
POINT CATEGORY TWO: PROJECT IMPACT
A-10
I.
Project impact is evaluated in accordance with the following
general KCCDAP objectives :
1 . To create, expand or improve public facilities.
2 . To create new permanant or temporary housing opportunities,
rehabilitate existing housing, or improve the effectiveness
of existing housing in an effort to prevent or eliminate
slums or blight.
3 . To obtain the requisite information for best implementing (1)
and /or (2) above.
Point assignment in this category is generally based on to what
degree the existing problems constitute a threat to the health,
safety, or economic welfare of those persons affected.
Additionally, the evaluation process will determine to what
extent the proposed activities will either help to solve these
problems or create a situation beneficial to a given population' s
health, safety and economic welfare.
Examples of projects receiving a maximum or near maximum point
assignment in this category are the extension of storm sewers to
an area in which a significant number of households or businesses
experience regular flooding, road improvements to alleviate
debilitating traffic congestion, or the development of parklands
in an area with a significant need for open space and recreation
facilities.
Kane County recognizes also that, although possibly less
immediate, sound planning, engineering, feasibility and other
such studies may have substantial positive impact on a local
jurisdiction and therefore, where appropriate, these projects may
receive high scores in this category.
Other issues within the "project impact" category which will
afford the applicant favorable consideration are described below.
Protects with regional or multi-jurisdictional impact: In
accordance with the County' s position of encouraging
intergovernmental cooperation, joint applications, or
applications submitted by one agency which are endorsed by
another will be afforded additional consideration in the
evaluation process.
Leveraging of Local Funds: It is required that all applications
for KCCDAP funds show no less than a dollar per dollar cash match
from locally generated funding. However, when an applicant
increases its local leverage of funds to an amount comprising
more than 50% of the total project cost, additional credit will
be given the application during evaluation.
Distribution Equity: Kane County recognizes the overall benefit
to make funding available to as many eligible applicants as
possible over time. Therefore, organizations submitting
applications for KCCDAP funding who have not previously received
funding will be given additional consideration.
A-11
A
Historic Preservation: In accordance with the County' s continued
concern for preserving its historic character , projects which
have as an elementthe preservation of historic, archaelogical ,
or cultural characteristics within the county will be favorably
considered.
Environmental Protection and Energy Conservation: Projects which
will result in the protection of our natural environment,
particularly those addressing solid waste management needs , or
conservation of energy will be favorably considered.
POINT CATEGORY THREE: PROJECT READINESS AND APPLICANT' S PAST
PERFORMANCE
The points assigned in this category are designed to encourage
project readiness. Two point matrices have been developed. The
first asigns points based on two components of readiness which
are: (1) the status of engineering, plans or the detail of
description of planning projects (e.g. , the status of the request
for proposal) : and (2) the obstacles that could stand in the way
of completion within one year.
Evaluating a project in terms of its readiness and
implementability will generally follow the matrix below.
However, the points shown are not necessarily limiting but rather
are given for instructional purposes only. It should be further
noted here that each application will be reviewed according to
the type of project proposed and judged on its own merits.
POINTS FOR PROJECT READINESS
Preliminary RFP/ Preliminary RFP/ Final RFP/
Plan/ Plan/ Plan/
Engineering Engineering Engineering
Not Complete Complete Complete
No Significant
Obstacles 14 16 20
Moderate Obstacles 6 8 12
Severe Obstacles 0 2 4
Obstacles in the way of completion will be strongly considered by
staff in making its preliminary evaluation. Clearer definition
of these categories are as follows:
No Significant Obstacles: The project will be considered to have
no significant obstacles if the project appears to be ready for
immediate start-up. Indicators of this level of readiness
include but are not limited to the following:
A-12
A. The applicant currently owns or is in control of the land
where the project will be located (or is very flexible
regarding the site to be purchased) .
B. The project is consistent with applicable regulations and
ordinances (e.g. , zoning or environmental concerns) .
C. Applicant controls operating funds and in fact has the
immediate funds readily available.
D. Special assessments or taxing districts are set up (if
applicable) .
Moderate Obstacles: These obstacles are those that would not
allow immediate start-up of the project. That is, there are
relatively minor activities which need to be completed.
Indicators of this level of readiness may include those given
below. However, these will not be 'considered as significant
obstacles if (1) there is substantial written evidence that these
activities would be complete in less than 90 days, or (2) the
applicant has phased the project so that these activities may be
completed before the applicable project components are due for
completion.
A. The applicant needs to acquire a small number of parcels or
easements in specific locations.
B. Rezoning of property is required.
C. The applicant still needs to set up the special assessments
or taxing district (if applicable) .
D. Operating funds are available, but applicant has not received
them.
Severe Obstacles: Obstacles are considered severe if it is
likely that preliminary activities will delay start-up by several
months. These activities may include the following.
A. The applicant needs to acquire a large number of parcels.
•
B. There are major legal or project set-up issues that could
take a substantial amount of time to resolve.
C. Applicant does not have operating funds or any sources to
apply for these funds.
Also taken into consideration for ongoing or phased projects is
the amount of funding available from previous cycle commitments.
To avoid "stockpiling" of funds, the applicant should request
only the amount of funds they can reasonably expect to expend
during the coming year. Applying for new funds for these types
of projects when substantial funding from previous years is still
available will be considered as a substantial obstacle affecting
the completion of the new project. Whether the obstacle is
considered moderate or severe is dependent on the amount of funds
remaining from the previous commitment.
A-13
A second matrix assigns points to be subtracted from the above
points based on past performance (if any) . The two components of
performance are (1) the degree to which obstacles have been
addressed and dealt with appropriately and in a timely fashion,
and (2) the applicant' s record in reporting project progress. In
the table below, we have termed the first component above as
"effectiveness" . The maximum points subtracted would be ten, and
the final readiness score cannot be less than zero. Again, the
matrix shown below is provided for instruction to applicants and
is not wholing limiting in the evaluation process itself.
POINTS SUBTRACED FROM READINESS
FOR PAST PERFORMANCE
Good Inconsistent Poor
Reporting Reporting Reporting
Record Record Record
High
Effectiveness 0 1 2
Moderate
Effectiveness 4 5 6
Low
Effectiveness 4 9 10
Definitions of the above are listed below. Applicants who have
not previously implemented a project will be awarded points
solely on the basis of project readiness.
High Effectiveness: These Grantees take appropriate action in
dealing with problems and obstacles and do it in a timely manner;
they take action early in the Grantee Agreement period making a
substantial effort to complete the project on time. They rarely
need project extensions, and when they do, it is for a minor part
of the project. These Grantees are also concerned about managing
the project in accordance with KCCDAP rules , and rarely have
problems within their control that require corrective action.
Evidence of a highly effective Grantee is that, barring any
unforeseen circumstance, the implementation schedule has been
followed.
Moderate Effectiveness: These Grantees usually take appropriate
action, but action seems to be delayed by two months or more from
what would be considered timely, or the Grantee has not taken
action early in the agreement period and the projects have been
behind schedule. Project extensions are usually required for
major components of the project. In addition, these Grantees may
take timely action, but often act inappropriately and actions
have to be corrected later. Evidence of a moderately effective
Grantee would include incomplete projects from more than one
program year back when implementation obstacles are not severe.
A-14
Low Effectiveness: These Grantees have given the CDAP project a
very low priority. Very little action is taken throughout the
Agreement period. Grantees with low effectiveness could have
imcomplete projects from more than two program years back.
Good Reporting Record: Quarterly project reports are usually up
to date and on time. The County Development staff is always kept
abreast of project developments.
Inconsistent Reporting Record: Quarterly project reporting is
inconsistent. Staff sometimes has to call to find out status.
Poor Reporting Recording: Quarterly progress reports are rarely
submitted. Staff rarely knows the status of the project and must
call or write to find out what actions are being taken.
A-15
EVALUATION SHEET
APPLICANT:
SPONSOR:
PROJECT:
TOTAL COST: KCCDAP REQUEST:
PROJECT AND PROPOSED ACTIVITIES ELIGIBLE FOR FUNDING: Yes_ NO
CONFORMANCE WITH COUNTY AND/OR LOCAL PLANS: POINTS
Dual Conformance
Conforms to Either County or Local Plans
Not Cited But Valid Argument Made
Not Cited, Valid Argument Not Made
Contradictory to Existing Plans
Subtotal (20 pts. max)
PROJECT IMPACT
General Impact (e.g. positive effect)
Specific Impact
Regional or Multi-Jurisdictional Impact
Local Leveraging of Funds Greater Than 50% of Total
Distribution Equity
Historic Preservation
Environmental Protection
Energy Conservation
Other
Subtotal (20 pts. max)
READINESS AND PAST PERFORMANCE
Project Readiness
Past Performance (To Be Subtracted from Readiness)
Subtotal (20 pts. max)
TOTAL SCORE
A-16
'4tr'