Loading...
HomeMy WebLinkAbout87-0514 Sinnett Builders 77- 6511. THE AMERICAN INSTITUTE OF ARCHITECTS *11*. 10 AIA Document A101 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a STIPULATED SUM 1977 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION Use only with the 1976 Edition of AIA Document A201, General Conditions of the Contract for Construction. This document has been approved and endorsed by The Associated General Contractors of America. AGREEMENT made as of the Fourteenth day of May in the year of Nineteen Hundred and Eighty-seven. BETWEEN the Owner: City of Elgin 150 Dexter Court Elgin, Illinois 60120 and the Contractor: Sinnett Builders, Inc. W. Highland Avenue, P.O. Box 146 Elgin, Illinois 60120 The Project: Renovations to Community Crisis Center 37 South Geneva Street Elgin, Illinois 60120 The Architect: Kaltenbach and Ferenc 17 Douglas Avenue Elgin, Illinois 60120 The Owner and the Contractor agree as set forth below. Copyright 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967,1974, © 1977 by the American Institute of Architects, 1735 New York Avenue, N.W., Washington, D. C. 20006. Reproduction of the material herein or substantial quotation of its provisions without permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 1 ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, all Addenda issued prior to and all Modifications issued after exe- cution of this Agreement. These form the Contract, and all are as fully a part of the Contract as if attached to this Agreement or repeated herein. An enumeration of the Contract Documents appears in Article 7. ARTICLE 2 THE WORK The Contractor shall perform all the Work required by the Contract Documents for (Here insert the caption descriptive of the Work as used on other Contract Documents.) Renovations to the Community Crisis Center, 37 South Geneva Street (Franklin School) , Elgin, Illinois. ARTICLE 3 TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION The Work to be performed under this Contract shall be commenced upon notification to proceed and, subject to authorized adjustments, Substantial Completion shall be achieved not later than one hundred and eighty-two das thereafter. (Here insert any special provisions for liquidated damages relating to failure to complete on time.) AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 2 • • ARTICLE 4 CONTRACT SUM The Owner shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order as provided in the Contract Documents, the Contract Sum of Three Hundred Thirty—nine Thousand, Seven Hundred Thirty—five and no/100 Dollars ($339,735.00) The Contract Sum is determined as follows: (State here the base bid or other lump sum amount,accepted alternates,and unit prices,as applicable.) Base Bid $339,735.00 Contract Sum $339,735.00 ARTICLE 5 PROGRESS PAYMENTS Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as pro- vided in the Contract Documents for the period ending the last day of the month as follows: Not later than fifteen days following the end of the period covered by the Application for Payment ninety percent ( 90 %) of the portion of the Contract Sum properly allocable to labor, materials and equipment incorporated in the Work and ninety percent ( 90 %) of the portion of the Contract Sum properly allocable to materials and equipment suitably stored at the site or at some other location agreed upon in writing,for the period covered by the Application for Payment, less the aggregate of previous payments made by the Owner; and upon Substantial Completion of the entire Work, a sum sufficient to increase the total payments to ninety—five percent ( 95 %) of the Contract Sum, less such amounts as the Architect shall determine for all incomplete Work and unsettled claims as provided in the Contract Documents. (If not covered elsewhere in the Contract Documents,here insert any provision for limiting or reducing the amount retained after the Work reaches a certain stage of completion.) Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing at the place of the Project. (Here insert any rate of interest agreed upon.) (Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Contractor's principal places of business, the location of the Project and elsewhere may affect the validity of this provision.Specific legal advice should be obtained with respect to deletion, modification, or other requirements such as written disclosures or waivers.) AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 3 • ' ARTICLE 6 FINAL PAYMENT Final payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by the Owner to the Contractor when the Work has been completed, the Contract fully performed, and a final Certificate for Payment has been issued by the Architect. ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 Terms used in this Agreement which are defined in the Conditions of the Contract shall have the meanings designated in those Conditions. 7.2 The Contract Documents,which constitute the entire agreement between the Owner and the Contractor,are listed in Article 1 and, except for Modifications issued after execution of this Agreement, are enumerated as follows: (List below the Agreement,the Conditions of the Contract (General,Supplementary,and other Conditions), the Drawings, the Specifications, and any Addenda and accepted alternates,showing page or sheet numbers in all cases and dates where applicable.) Instructions to Bidders, dated March 12, 1987 General Conditions, dated March 12, 1987 Supplementary General Conditions, dated March 12, 1987 Specifications, dated March 12, 1987 Drawings, Sheets A2 through A9, ME1 through ME3, FP1 through FP5, inclusive, dated March 12, 1987. Addenda #1, dated March 20, 1987 Addenda #2, dated April 8, 1987 Contractor's Proposal, dated April 21, 1987 This Agreement, dated May 14, 1987 This Agreement entered into as of the day and year first written above. OWNER CONTRACTOR CITY OF ELGIN SINNETT BUILDERS INC. � y y ye;14, Sam — -72-1 s. AIA DOCUMENT A101 • OWNER-CONTRACTOR AGREEMENT • ELEVENTH EDITION • JUNE 1977 • AIA® ©1977 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A101-1977 4 - a_. TAB STOPSAT1WROWSF Of CERTIFICATE F NSURANCE M t SSUE DATE MM/DD/Y 5—2 8—8 7 PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Ar Insurance Correlators Inc. ,. 1972 Larkin Avenue COMPANIES AFFORDING COVERAGE Elgin IL 60120 COMPANY A LETTER Casualty Insurance Company ., COMPANY '. INSURED LETTER 9 " American States Insurance v` COMPANY T; LETTER c Statewide Insurance Company Sinnett Builders, Inc. COMPANY D P 0 Box 146 LETTER Elgin IL 60121 0146 COMPANY LETTER E -.VERAGW 'fir - - -- :r k.,,. '''•••„ s'i • THIS IS TO CERTIFY THAT POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY r:;'_. BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS,AND CONDI- TIONS OF SUCH POLICIES. CO POLICY EFFECTIVE POLICY EXPIRATION LIABILITY LIMITS IN THOUSANDS _TR TYPE OF INSURANCE POLICY NUMBER DATE(MM/DD/YYI DATE(MM/DDYY) EACH OCCURRENCE AGGREGATE GENERAL LIABILITY GAL8623275 12-31-86 12-31-87 IN.IURY x COMPREHENSIVE FORM GAL8623275 $ A _....x PREMISES/OPERATIONS PROPERTY UNDERGROUND DAMAGE $ $ _ EXPLOSION 8 COLLAPSE HAZARD x PRODUCTS/COMPLETED OPERATIONS x CONTRACTUAL COMB NED $ 1 ,000 $ I ,000 x INDEPENDENT CONTRACTORS BROAD FORM PROPERTY DAMAGE 4: PERSONAL INJURY PERSONAL INJURY $ , 1 ,000 AUTOMOBILE LIABILITY BDDc_Y A.IUR, $ B ANY AUTO (PER PERSOi ALL OWNED AUTOS(PRIV PASS) INJURY � ALL OWNED AUTOS�THE R PRI THANASS 01 PP063231 10 12-31-86 12-31-87 IPER ACCIDENT $ HIRED AUTOS PROPERTY NON OWNED AUTOS DAMAGE a: GARAGE LIABILITY ;'' BI&PO COMBINED I,, 6 EXCESS LIABILITY C 4UMBRELLAFORM U187100160 1-27-87 1-27-88 COMBINED $ 1 ,000 $ 1 ,000 J. OTHER THAN UMBRELLA FORM STATUTORY WORKERS' COMPENSATION . $500 (EACH ACCIDENT) AND WC86023275 12-31-86 12-31-87 Scat (DISEASE POLICY LIMIT) A EMPLOYERS' LIABILITY $ , (DISEASE EACHEMPLOYEE) OTHER 6,4 DESCRIPTION OF OPERATIONS/LOCATIONSNEHICLES/SPECIAL ITEMS Job:Construction of the Community Crisis Center =-TIFICATE HOLDER ,$ .f. .M CELLATION -4 IV SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EX- City of Elgin PIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO 150 Dexter Court MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY •- Elgin IL 60120 OF ANY KIND UPON THE COMPANY, ITS AGENTS OR REPRESENTATIVES. ' iralZ/`ZE I(i..T • I> • tit: CORD,25 0184) .�,,x ..,,.1 /'�� / CORD le" r..r�a-�" .,.°�..Ys t v�Y i �L� , trt.,p +, rs+`:y�y ..M4, }.,:'"^":'�'4r•,+! � t't`-�... N THE AMERICAN INSTITUTE OF ARCHITECTS 41114 Bond No, BISC79351 AIA Document A311 Performance Bond KNOW ALL MEN BY THESE PRESENTS: that SINNETT BUILDERS, INC. P. 0. Box 146 (Here insert full name and address or legal title of Contractor) Elgin, Illinois 60120 as Principal, hereinafter called Contractor, and, STATEWIDE INSURANCE COMPANY P. 0. Box 799 (Here insert full name and address or legal title of Surety) Waukegan, Illinois 60079 as Surety, hereinafter called Surety, are held and firmly bound unto the CITY OF ELGIN 150 Dexter Court (Here insert full name and address or legal title of Owner) Elgin, Illinios 60120 as Obligee, hereinafter called Owner, in the amount of Three Hundred Thirty-nine Thousand Seven Hundred Thirty-five and No/100 Dollars ($ 339,735.00 ), for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated May 14,19 87 , entered into a contract with Owner for (Here insert full name,address and description of project) General construction of Community Crisis Center 37 S. Geneva Street, Elgin, Illinois in accordance with Drawings and Specifications prepared by KALTENBACH FERENC 17 Douglas (Here insert full name and address or legal title of Architect) Elgin, Illinois 60120 which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. A1A DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA ® fEBRUARY 1970 ED. •THE AMERICAN INSTITUTE OF ARCHITECTS, 17iS N.Y. AVE., N.W.,WASHINGTON, D. C. 20006 1 PERFORMANCE BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said Contract, then this obligation shall be null and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or defaults under the contract or contracts of completion extension of time made by the Owner. arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; Whenever Contractor shall be, and declared by Owner but not exceeding, including other costs and damages to be in default under the Contract, the Owner having performed Owner's obligations thereunder, the Surety for which the Surety may be liable hereunder, the amount may promptly remedy the default, or shall promptly set forth in the first paragraph hereof. The term "balance of the contract price," as used in this paragraph, shall 1) Complete the Contract in accordance with its terms mean the total amount payable by Owner to Contractor and conditions, or under the Contract and any amendments thereto, less the amount properly paid by Owner to Contractor. 2) Obtain a bid or bids for completing the Contract in Ariy suit under this bond must be instituted before accordance with its terms and conditions, and upon de the expiration of two (2) years from the date on which termination by Surety of the lowest responsible bidder, final payment under the Contract falls due. or, if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible No right of action shall accrue on this bond to or for bidder, arrange for a contract between such bidder and the use of any person or corporation other than the Owner, and make available as Work progresses (even Owner named herein or the heirs, executors, adminis- though there should be a default or a succession of trators or successors of the Owner. Signed and sealed this 27th day of May 19 87 SINNETT BUILDERS, INC. • Principal) )1 (Seal) faLci (Witness) (Title) STATEWIDE INSURANCE COMPANY (Sure•!},) (Seal) 1 E1 i zab h A.RyalhWitness) ` Richard D. Jones wtl`')Attorney-in-Fact AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA Ca. FEBRUARY 1970 ED.•THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE.,N.W.,WASHINGTON,D. C.20006 2 • 1 . 1• THE AMERICAN INSTITUTE OF ARCHITECTS Bond No. BISC79351 AIA Document A311 Labor and Material Payment Bond THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT KNOW ALL MEN BY THESE PRESENTS: that SINNETT BUILDERS, INC. P. 0. Box 146 (Here insert full name and address or legal title of Contractor) Elgin, Illinois 60120 as Principal, hereinafter called Principal, and, STATEWIDE INSURANCE COMPANY P. 0. Box 799 (Here insert full name and address or legal title of Surety) Waukegan, Illinois 60079 as Surety, hereinafter called Surety, are held and firmly bound unto the CITY OF ELGIN 150 Dexter Court (Here insert full name and address or legal title of Owner) Elgin, Illinois 60120 as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined, in the amount of Three Hundred Thirty-nine Thousand SevenHundred Thirty-five and No/100--- (Here insert a sum equal to at least one-half of the contract price) Dollars ($ 339,735.00 for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by written agreement dated May 14, 19 87, entered into a contract with Owner for (Here insert full name,address and description of project) General Construction of Community Crisis Center 37 S. Geneva Street, Elgin, Illinois in accordance with Drawings and Specifications prepared by KALTENBACH FERENC (Here insert full name and address or legal title of Architect) 17 Douglas Elgin, Illinois 60120 which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AlA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • MA ® FEBRUARY 1970 ED.•THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE., N.W.,WASHINGTON, D. C. 20006 3 LABOR AND MATERIAL PAYMENT BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the ( Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject,however, to the fol- lowing conditions: 1. A claimant is defined as one having a direct con- accuracy the amount claimed and the name of the party tract with the Principal or with a Subcontractor of the to whom the materials were furnished, or for whom Principal for labor, material, or both, used or reasonably the work or labor was done or performed. Such notice required for use in the performance of the Contract, shall be served by mailing the same by registered mail labor and material being construed to include that part of or certified mail, postage prepaid, in an envelope ad- water, gas, power, light, heat, oil, gasoline, telephone dressed to the Principal, Owner or Surety, at any place service or rental of equipment directly applicable to the where an office is regularly maintained for the trans- Contract. action of business, or served in any manner in which legal process may be served in the state in which the 2. The above named Principal and Surety hereby aforesaid project is located, save that such service need jointly and severally agree with the Owner that every not be made by a public officer. claimant as herein defined, who has not been paid in b) After the expiration of one (1) year following the full before the expiration of a period of ninety (90) date on which Principal ceased Work on said Contract, days after the date on which the last of such claimant's it being understood, however, that if any limitation em- work or labor was done or performed, or materials were bodied in this bond is prohibited by any law controlling furnished by such claimant, may sue on this bond for the construction hereof such limitation shall be deemed the use of such claimant, prosecute the suit to final to be amended so as to be equal to the minimum period judgment for such sum or sums as may be justly due of limitation permitted by such law. claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses c) Other than in a state court of competent jurisdiction of any such suit. in and for the county or other political subdivision of the state in which the Project, or any part thereof, is 3. No suit or action shall be commenced hereunder situated, or in the United States District Court for the district in which the Project, or any part thereof, is sit- by any claimant: uated, and not elsewhere. a) Unless claimant, other than one having a direct contract with the Principal, shall have given written 4. The amount of this bond shall be reduced by and notice to any two of the following: the Principal, the to the extent of any payment or payments made in good Owner, or the Surety above named, within ninety (90) faith hereunder, inclusive of the payment by Surety of 1 days after such claimant did or performed the last of mechanics' liens which may be filed of record against the work or labor, or furnished the last of the materials said improvement, whether or not claim for the amount for which said claim is made, stating with substantial of such lien be presented under and against this bond. 1 Signed and sealed this 27th day of Mays ' 'I r . ` SINNETT BUILDERS,Ii k ' r N, (Principal) 1s ii 1 II 72-:4-4/..-1 ' l (Witness) )11' ' (Title) • STATEWIDE INSURANCE COMPANY (Surety) (Seat)',r4�' ,---'‘,,,4_04,4211--61,./ di er-f4--/ (Wanes%)• r s' E11zbeth A. Ryan wide) '.--,4-:' , ,,e,,?. Richard D. Jone Attern t act AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • MA ® �. FEBRUARY 1970 ED.•THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE.,N.W.,WASHINGTON,D.C.2tJ � �� )'• xfr,. I • III; STATEWIDE INSURANCE COMPANY P.O. BOX 799 • 325 NORTH GENESEE ST. WAUKEGAN, ILLINOIS 60079-0799 312/662-0073 POWER OF ATTORNEY I I KNOW ALL MEN BY THESE PRESENTS, That STATEWIDE INSURANCE COMPANY,an Illinois stock insurance corporation, does make constitute and appoint R. L. DRAKE, RICHARD D. .:ONES AND JAt1ES E. SCHRAM EACH OF WAUKFGAN, ILLINOIS its true and lawful Attorney(s)-in-Fact, with full power and authority for and on behalf of the company as surety,to execute and deliver and affix the seal of the 1 company thereto if a seal is required, bonds,undertakings,recognizances or other written obligations in the nature thereof as follows: ALL WR IT I EN INSTRUMENTS and to bind STATEWIDE INSURANCE COMPANY thereby,and all of the acts of said Attorney(s)-in-Fact,pursuant to these presents,are ratified and confirmed. This Power of Attorney is granted and is signed and sealed under and by the authority of the following Resolution adopted by the Board of Directors of the STATEWIDE INSURANCE COMPANY,Waukegan, Illinois,at a meeting duly called and held on the 27th day of September, 1979. "RESOLVED, that the Chairman of the Board, the Vice Chairman of the Board, the President, an Executive Vice President, a Senior Vice President or a Vice President of the Company be,. and that each or any of them hereby is,authorized to execute Powers of Attorney qualifying the attorney named in the given Power of Attorney to execute in behalf of STATEWIDE INSURANCE COMPANY, Waukegan, Illinois, bonds, undertakings and all contracts of suretyship;and that an Assistant Vice President, a Secretary or an Assistant Secretary be,and that each or any of them hereby is,authorized to attest the execution of any such Power of Attorney,and to attach hereto the seal of the Company. FURTHER RESOLVED, that the signatures of such officers and the seal of the Company may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be valid and binding upon the ' Company when so affixed and in the future with respect to any bond,undertaking or contract of suretyship to which it is attached." In Witness Whereof, the STATEWIDE INSURANCE COMPANY, Waukegan, Illinois, has caused its official seal to be hereunto affixed and these presents to be signed by one of its Vice Presidents and attested by one of its Secretaries this 2NDlay of MARCH , 1987 I ATTEST: STATEWIDE INSURANCE COMPANY I ,�O .K6:fl AN.F�.• 1(5 2/, Ziee.. Ralph 0- J\I\ 'CIW.Swank,Jr., Secretary '`;�. . \ '.5,-•(1,..11 . - °`s By P ,,,•... R.L. Drake, Vice President STATE OF ILLINOIS 1 COUNTY OF LAKE ) ss' On this 2 NDay of MARCH , 1987 personally came before me,R.L.Drake and Ralph W.Swank,Jr.to me known to be the individuals and officers of the STATEWIDE INSURANCE COMPANY who executed the above instrument, and they each acknowledged the execution of the same, and being by me duly sworn, did severally depose and say: that they are the said officers of the corporation aforesaid, and that the seal affixed to the above instrument is the seal of the corporation, and that said corporate seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority of the Board of Directors of said corporation. .4414-. of // 9 •," . /4;204,(.../' :•NOT AR••2 1. PUBI,C Elizabeth yan, Notary Public •.. My Commission Expires; , •,,.f•cou NiV •......... "' 3RD OF JULY, 1990 CERTIFICATE I, the undersigned Assistant Secretary of the STATEWIDE INSURANCE COMPANY, an Illinois corporation, CERTIFY that the foregoing and attached Power of Attorney remains in full force and has not been revoked, and furthermore, that the provisions of the By-Laws of the company and the Resolutions of the Board of Directors set forth in the Power of Attorney,are now in force. Signed and sealed at the City of Waukegan thc,/_____, is 27th day of Mayrn:: „.....s..,....... ....„,..:.:,„,... 4. fr''..-------9.„( zA,1/4..\j13 1979 ;llo;s Ralph W.Swank, Assistant Secretary