Loading...
HomeMy WebLinkAbout86-0424 Aluminum Building Corp. ,r; _ • • , • • • ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement. Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, all Addenda issued prior to execution of this Agreement and all Modifications • issued subsequent thereto. These form.the: Contract, are all are as fully a part of the Contract as if attached. to this Agreement or repeated herein. An enumeration of the Contract Documents appears in Article 7. • ARTICLE 2 THE WORK The Contractor shall perform all the Work required by the. Contract Documents for (Men insert the caption desu{pt,.•e or the Work ar used on other Conrrstr Documents-1 Furnish arx3 install 305 AEC 700 A2-HP-60 in the Senior Citizens High Rise. Existing windows and debris related to job shall be removed from site. All windows to be trimmed with necessary extruded trim. All windows to be caulked completely. • • ARTICLE. 3• ? . TIME OF COMMENCEMENT AND COMPLETION The Work to be performed under this Contract shall be commenced 45 days frau date contract signed. • and completed 90 days from ccarmrtercement (Here insert ally special prori)ions for liquidated dernag-s relatin; to Iaiisrsz to con p:ete on time.i • • • ?;3r • • • • AEA DOCUMENT A1t#1 • OWNER-CONTRACTOR AGREEMENT • JANUARY'1V4 EDITION • MAD • 01974 SME AMERICAN INSTITUTE Of ARCHITECTS, 1711 NEW YORK Afl. N:W., WASHINGTON. 0.C sum 4 • • • • ARTICLE 4 CONTRACT SUM • • The Owner shall pay the Contractor for the performahce of the Work, subject to additions and deductions by Change Order as provided in the Conditions of the.Contract, in current funds, the Contract Sum of • Eighty—six Thousand Six Hundred Sixty—two Dollars 80/00 • Mat,Ave the lump sum amount.unit pieces.or both,v dewed I $86,662.80 ' • ARTICLE S PROGRESS PAYMENTS Based upon Applications for Payment submitted to•the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as pro- • vided in the Conditions of the Contract as follows: On or about the • day of each month per cent of the proportion of t�MietMt it )um property allocable to labor, materia sf and equipment tncvrporated in the Work and : per cent of the portion of the Contract Sum properly allocable to materials and equipment suitadry stored at the site or at some other location agreed upon in writing by the parties, up to days prior to the date on which the Application for Payment is submitted. less the aggregate 'or previous payments in each case; and upon Substantial Completion of the entire Work, a sum sufficient to increase - the total payments to ' per cent of the Contract Sum, less such retainages as the Architect shall determine for alt•-rr.tuiiiptet d unsettled claims. UI not co.e,ed et,r..•here,n the Contract Documenu, herr insert any prorisidf 6r I nn,ties or•ed,c:,Y the amount retained:carr the Kori,:acnes a certain stair of completion-) Payments will be made on the 10th of each month for all installation eanpleted by the end of each month. . • • • Any moneys not paid when due to either party under this Contract shall bear interest at the 100E rate in tau at the place of the Project. - r AIA DOCUMENT ATV • OWNIR-CONTRACTOR AGRIISKNT • IANU Y 1S/ ID/TION • AIA, • *WA ' MI AMIR/CAN INSTITUTE Of AI.tC$ITECTS. 1735 NEW TORO AW.KW.. WASHINGTON. O.C. MI . i • , , - - . i . -W`'' PAYMENT . Final payment, constituting the entire unpaid balance of the Contract S . shalt be paid by the Owner.to the Contractor .. days after Substantial Completion of the Work unless otherwise stipulated in the Certificate of Substantial Completion, provided the Work has then been completed. the Contract fully performed, and a final Certificate for Payment has beep issued by the Architect. .. • ARTICLE 7 MISCELLANEOUS PROVISIONS - 7.1 Terms used in this Agreement which are defined in the Conditions of the Contract shall have the meanings designated in those Conditions. 7.2 The Contract Documents,which constitute the entire agreement between the Owner and the Contractor,are listed in Article 1 and,except for Modifications issued after execution of this Agreement,are enumerated as follows: rust below Me Agreement. Conditions of the Connie? (General,Suppremesearr, acrd othw Condiriorssi Drawingr. SpeciFcarions. Addenda and receit(d- Alsernatn,showing pane or sheet numbers in all cases and dares where tpll:cabki i This agreement includes: • 1.) 100 percent labor performance band 2.) Complete installation with trim material and caulk 3.) mal and disposal of all debris frac job site 4.) A one (1) year guarantee of workmanship • 5.) Complete Comprehensive and Liability Insurance • 6.) Total catipliance with the Davis- Act 7.)- Total compliance with E.E.O. requirements as set forth at 41 C.F.R. Section 1-12.803 • 8.) Supervision by factory trained personnel to assure installation in aroordarce with 's recc ttmsndaticros -rr This Agreement executed the day and year first written above. OWNER- Housing Authority of Elgin CONTRACTOR Araninun • • : s•, •0111 grL— . City a ( ,,a.4__ Sales Mana • ger. &A OOCUttNT A • Ow dl.c0P411 ACtOtt Ace ft041147 •~MUM WSTLON • • O'1104. s.e 4 I It s4RiCN4 t TRU S co A taCT� U3$ et vO NAL.111.W, sri.wAt C l • • • THE AMERICAN INSTITUTE OF ARCHITECTS 41! AIA Document A312 Performance Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Aluminum Building Corporation TSE TRAVELERS INDEMNITY COMPANY 12280 Burt Road 26555 Evergreen Road Detroit, MI 48228 Southfield, MI 48076 OWNER (Name and Address): City of Elgin 150 Dexter Court Elgin, IL 60120 CONSTRUCTION CONTRACT • Date: Oct. 13, 1986 Amount: $86,662.80 • Description (Name and Location): Installation of Replacement Windows at Central Park Tower BOND Date (Not earlier than Construction Contract Date): 11/17/86 Amount: $86,662.80 Modifications to this Bond: a None O See Page 3 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) ALUNIINUM BUILDING CORPORATION THE TRA' ^+:. I n D I P s►a r A y Signature: Signature: ����lGl� �. r(SO&_ Name and Title: Name and Title: Richard E. Seaman, Attorney—in— COUNTERSIGNED_ BY: c� Fact (Any additional signatures appear on page 3) Thomas 0. • = : =, LL Resident Agent (FOR INFORMATION ONLY—Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or William T. O'Brien Agency other party): 24225 W. 9 Mile, Suite 205 Southfield, MI 48034 • 1 MA DOCUMENT A312• PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED. •AIA a THE AMERICAN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVE., N.W.,WASHINGTON, O.C. 20006 A312-1984 1 • • • 1 The Contractor and the Surety, jointly and severally, which it may be liable to the Owner and, as bind themselves, their heirs, executors, administrators, soon as practicable after the amount is deter- successors and assigns to the Owner for the performance mined, tender payment therefor to the of the Construction Contract,which is incorporated herein Owner; or by reference. .2 Deny liability in whole or in part and notify the 2 If the Contractor performs the Construction Contract, Owner citing reasons therefor. the Surety and the Contractor shall have no obligation 5 If the Surety does not proceed as provided in Paragraph under this Bond, except to participate in conferences as 4 with reasonable promptness,the Surety shall be deemed provided in Subparagraph 3.1. to be in default on this Bond fifteen days after receipt of an 3 If there is no Owner Default, the Surety's obligation additional written notice from the Owner to the Surety under this Bond shall arise after: demanding that the Surety perform its obligations under • 3.1 The Owner has notified the Contractor and the this Bond, and the Owner shall be entitled to enforce any remedy available to the'Owner. If the Surety proceeds as Surety at its address described in Paragraph 10 below provided in Subparagraph 4.4,and the Owner refuses the that the Owner is considering declaring a Contractor payment tendered or the Surety has denied liability, in Default and has requested and attempted to arrange a whole or in part,without further notice the Owner shall be conference with the Contractor and the Surety to be entitled to enforce any remedy available to the Owner. held not later than fifteen days after receipt of such notice to discuss methods of performing the Construc- 6 After the Owner has terminated the Contractor's right tion Contract. If the Owner, the Contractor and the to complete the Construction Contract, and if the Surety Surety agree,the Contractor shall be allowed a reason- elects to act under Subparagraph 4.1, 4.2, or 4.3 above, able time to perform the Construction Contract, but then the responsibilities of the Surety to the Owner shall such an agreement shall not waive the Owner's right,if not be greater than those of the Contractor under the any,subsequently to declare a Contractor Default; and Construction Contract, and the responsibilities of the 3.2 Owner a Default and Owner to the Surety shall not be greater than those of the 3.2 Thely terminated has the declaredContractor'sContractor rto Default and e Owner under the Construction Contract.To the limit of the foramount of this Bond, but subject to commitment by the the contract. Such Contractor Default shall not be de dared earlier than twenty days after the Contractor and Owner of the Balance of the Contract Price to mitigation of Sure- the Suretyhave received notice asprovidedtrin Sub- costs and damages on the Construction Contract,the ty is obligated without duplication for: paragraph 3.1; and • 3.3 The Owner has agreed to pay the Balance of the 6.1 The responsibilities of the Contractor for correc- tion of defective work and completion of the Construc- Contract Price to the Surety in accordance with the tion Contract; terms of the Construction Contract or to a contractor selected to perform the Construction Contract in actor- 6.2 Additional legal, design professional and delay dance with the terms of the contract with the Owner. costs resulting from the Contractor's Default, and re- 4 When the Owner has satisfied the conditions of Para suiting from the actions or failure to act of the Surety under Paragraph 4; and graph 3, the Surety shall promptly and at the Surety's ex- pense take one of the following actions: 6.3 Liquidated damages, or if no liquidated damages Arrange for the Contractor, with consent of the are specified in the Construction Contract,actual dam- 4.1ages caused by delayed performance or non-perfor- Owner, to perform and complete the Construction mance of the Contractor. Contract; or 4.2 Undertake to perform and complete the Construc- 7 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Con- tion Contract itself,through its agents or through inde- struction Contract, and the Balance of the Contract Price pendent contractors; or shall not be reduced or set off on account of any such 4.3 Obtain bids or negotiated proposals from unrelated obligations. No right of action shall accrue on qualified contractors acceptable to the Owner for a this Bond to any person or entity other than the Owner or contract for performance and completion of the Con- its heirs, executors, administrators or successors. struction Contract, arrange for a contract to be pre 8 The Surety hereby waives notice of any change,includ- pared for execution by the Owner and the contractor ing changes of time, to the Construction Contract or to selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a related subcontracts, purchase orders and other obliga- qualified surety equivalent to the bonds issued on the tions. Construction Contract, and pay to the Owner the 9 Any proceeding, legal or equitable, under this Bond amount of damages as described in Paragraph 6 in ex- may be instituted in any court of competent jurisdiction in cess of the Balance of the Contract Price incurred by the the location in which the work or part of the work is located Owner resulting from the Contractor's default; or and shall be instituted within two years after Contractor 4.4 Waive its right to perform and complete, arrange Default or within two years after the Contractor ceased for completion, or obtain a new contractor and with working or within two years after the Surety refuses or fails reasonable promptness under the circumstances: to perform its obligations under this Bond,whichever oc- curs first. If the provisions of this Paragraph are void or .1 After investigation, determine the amount for prohibited by law,the minimum period of limitation avail- ; AIA DOCUMENT A312• PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED. •AIA THE AMERICAN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVE., N.W.,WASHINGTON, D.C. 20006 A312-1984 2 able to sureties as a defense in the jurisdiction of the suit tractor of any amounts received or to be received by shall be applicable. the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, re- 10 Notice to.the Surety,the Owner or the Contractor shall duced by all valid and proper payments made to or on be mailed or delivered to the address shown on the sig- behalf of the Contractor under the Construction Con- nature page. tract. 11 When this Bond has been furnished to comply with a 12.2 Construction Contract:The agreement between statutory or other legal requirement in the location where the Owner and the Contractor identified on the sig- the construction was to be performed,any provision in this nature page, including all Contract Documents and Bond conflicting with said statutory or legal requirement changes thereto. shall be deemed deleted herefrom and provisions con- • forming to such statutory or other legal requirement shall 12.3 Contractor Default: Failure of the Contractor, be deemed incorporated herein. The intent is that this which has neither been remedied nor waived,to per- Bond shall be construed as a statutory bond and not as a form or otherwise to comply with the terms of the common law bond. Construction Contract. 12 DEFINITIONS 12.4 Owner Default: Failure of the Owner,which has neither been remedied nor waived, to pay the Con- 12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the tractor as required by the Construction Contract or to perform and complete or comply with the other terms Construction Contract after all proper adjustments thereof. have been made, including allowance to the Con- MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: MA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED. •AIA (a THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 3 • THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A312 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Aluminum Building Corporation THE TRAVELERS INDEMNITY COMPANY 12280 Burt Road 26555 Evergreen Road Detroit, MI 48228 Southfield, MI 48076 OWNER (Name and Address): City of Elgin 150 Dexter Court Elgin, IL 60120 CONSTRUCTION CONTRACT Date: Oct. 13, 1986 Amount: $86,662.80 Description (Name and Location): Installation of Replacement Windows at Central Park Tower BOND Date (Not earlier than Construction Contract Date): 11/17/86 Amount: $86,662.80 Modifications to this Bond: ►:A None O See Page 6 CCoONTRACTOR AS PRINCIPAL SURETY AI,�� BUILDING CORPOR4 i orporate Seal) Company: /' (Cor orate Seal) THE TRAVE NDDDIITY CO r Signature: Signature: CCf 49/I!'1,l'9t • Name and Title: Name and Title: Richard E. Seaman, Attorney—in- CO IGNED BY: Fact (Any additional signatures appear on page 6) `. (� • -Q/ , Resident Agent (FOR INFORMATION ONLY—Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or William T. O'Brien Agency other party): 24225 W 9 Mile, Suite 205 Southfield, MI 48034 AIA DOCUMENT A312• PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED. •AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON,D.C. 20006 A312.1984 4 • severally, 6 When the Claimant has satisfied the conditions of Para- 1 The Contractor and the Surety, jointly and a y, bind themselves, their heirs, executors, administrators, graph 4, the Surety shall promptly and at the Surety's ex- 1 successors and assigns to the Owner to pay for labor, pense take the following actions: . - materials and equipment furnished for use in the perfor- 6.1 Send an answer to the Claimant,with a copy to the ! mance of the Construction Contract,which is incorporated Owner,within-45 days after receipt of the claim,stating herein by reference. the amounts that are undisputed and the basis for chat- 2 With respect to the Owner,this obligation shall be null lenging any amounts that are disputed. and void if the Contractor: 6.2 Pay or arrange for payment of any undisputed 2.1 Promptly makes payment, directly or indirectly, amounts. t for all sums due Claimants, and I 7 The Surety's total obligation shall not exceed the 2.2 Defends, indemnifies and holds harmless the amount of this Bond,and the amount of this Bond shall be Owner from all claims, demands, liens or suits by any credited for any payments made in good faith by the Surety. person or entity who furnished labor, materials or i equipment for use in the performance of the Construc- 8 Amounts owed by the Owner to the Contractor under t tion Contract, provided the Owner has promptly noti- the Construction Contract shall be used for the perfor- fied the Contractor and the Surety (at the address de mance of the Construction Contract and to satisfy claims,if scribed in Paragraph 12) of any claims, demands, liens any, under any Construction Performance Bond. By the or suits and tendered defense of such claims,demands, Contractor furnishing and the Owner accepting this Bond, liens or suits to the Contractor and the Surety, and they agree that all funds earned by the Contractor in the provided there is no Owner Default. performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under 3 With respect to Claimants, this obligation shall be null this Bond,subject to the Owner's priority to use the funds and void if the Contractor promptly makes payment, di- for the completion of the work. rectly or indirectly, for all sums due. 9 The Surety shall not be liable to the Owner,Claimants ' 4 The Surety shall have no obligation to Claimants under or others for obligations of the Contractor that are unrelat- ` this Bond until: ed to the Construction Contract. The Owner shall not be 4.1 who are employed or have a direct liable for payment of any costs or expenses of any Claimant .1Claimants with the Contractor haved bygieen noticeaveto the under this Bond,and shall have under this Bond no obliga- contractSurety (at the address described in Paragraph 12) and tions to make payments to, give notices on behalf of, or sent a copy,or notice thereof,to the Owner,stating that otherwise have obligations to Claimants under this Bond. a claim is being made under this Bond and, with sub- 10 The Surety hereby waives notice of any change,includ- stantial accuracy, the amount of the claim. ing changes of time, to the Construction Contract or to 4.2 Claimants who do not have a direct contract with related subcontracts, purchase orders and other obliga- tions. the Contractor: .1 Have furnished written notice to the Con- 11 No suit or action shall be commenced by a Claimant tractor and sent a copy, or notice thereof, to under this Bond other than in a court of competent jurisdic- tion in the location in which the work or part of the work is the Owner, within 90 days after having last located or after the expiration of one year from the date(1) • performed labor or last furnished materials or on which the Claimant gave the notice required by Sub- equipment included in the claim stating,with paragraph 4.1 or Clause 4.2 (iii), or (2) on which the last substantial accuracy, the amount of the claim labor or service was performed by anyone or the last mate- and the name of the party to whom the mate- rials or equipment were furnished by anyone under the rials were furnished or supplied or for whom Construction Contract,whichever of(1)or(2)first occurs. the labor was done or performed; and If the provisions of this Paragraph are void or prohibited by .2 Have either received a rejection in whole or in law,the minimum period of limitation available to sureties part from the Contractor,or not received with- as a defense in the jurisdiction of the suit shall be applica- in 30 days of furnishing the above notice any ble. communication from the Contractor by which 12 Notice to the Surety,the Owner or the Contractor shall the Contractor has indicated the claim will be be mailed or delivered to the address shown on the sig- . paid directly or indirectly; and nature page.Actual receipt of notice by Surety,the Owner .3 Not having been paid within the above 30 days, or the Contractor, however accomplished, shall be suffi- '• have sent a written notice to the Surety(at the tient compliance as of the date received at the address address described in Paragraph 12)and sent a shown on the signature page. copy,or notice thereof, to the Owner, stating 13 When this Bond has been furnished to comply with a that a claim is being made under this Bond and statutory or other legal requirement in the location where enclosing a copy of the previous written notice the construction was to be performed,any provision in this furnished to the Contractor. Bond conflicting with said statutory or legal requirement 5 If a notice required by.Paragraph 4 is given by the Owner shall be deemed deleted herefrom and provisions con- to the Contractor or to the Surety,that is sufficient compli- forming to such statutory or other legal requirement shall ance. - be deemed incorporated herein. The intent is that this AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED. •AIA g THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W.,WASHINGTON, D.C.20006 A312-1984 5 I I --- . - • a. . G. • • Bond shall be construed as a statutory bond and not as a Construction Contract, architectural and engineering common law bond. services required for performance of the work of the 14 Upon request by any person or entity appearing to be a Contractor and the Contractor's subcontractors, and • potential beneficiary of this Bond, the Contractor shall all other items for which a mechanic's lien may be promptly furnish a copy of this Bond or shall permit a copy or equi in the jurisdictionfurnished.where the labor, materials to be made. or equipment were furnished. 15 DEFINITIONS 15.2 Construction Contract:The agreement between the Owner and the Contractor identified on the sig- 15.1 Claimant: An individual or entity having a direct nature page, including all Contract Documents and contract with the Contractor or with a subcontractor of changes thereto. the Contractor to furnish labor, materials or equip- 15.3 Owner Default: Failure of the Owner,which has ment for use in the performance of the Contract. The neither been remedied nor waived, to pay the Con- intent of this Bond shall be to include without limits tractor as required by the Construction Contract or to tion in the terms"labor, materials or equipment"that perform and complete or comply with the other terms part of water, gas, power, light, heat, oil, gasoline, thereof. telephone service or rental equipment used in the MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: AIA DOCUMENT A312• PERFORMANCE BOND AND PAYMENT BOND• DECEMBER 1984 ED. •AIA I THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W.,WASHINGTON, D.C. 20006 A312-1984 6 The Travelers Indemnity Company • • Hartford, Connecticut If necessary,validation of this power of attorney is available at (203) 277-7839. Collect calls will be accepted. POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That THE TRAVELERS INDEMNITY COMPANY, a corporation of the State of Connecticut, does hereby make, constitute and appoint Nancy Flynn, J. Layne, Connie McCullough, Joyce Marie Patterson, Richard E. Seaman, all of Southfield, Michigan, EACH its true and lawful Attorney(s)-in-Fact, with full power and authority, for and on behalf of the Company as surety, to execute and deliver and affix the seal of the Company thereto, if a seal is required, bonds, undertakings, recognizances, consents of surety or other written obligations in the nature thereof, as follows: Any and all bonds, undertakings, recognizances, consents of surety or other written obligations in the nature thereof and to bind THE TRAVELERS INDEMNITY COMPANY thereby, and all of the acts of said Attorney(s)-in-Fact, pursuant to these presents, are hereby ratified and confirmed. This appointment is made under and by authority of the following Resolutions adopted by the Board of Directors of THE TRAVELERS INDEMNITY COMPANY at a meeting duly called and held on the 1st day of November, 1985 which Resolutions are now in full force and effect: VOTED: That the Chairman of the Board, the President, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Corporate Secretary or any Department Secretary may appoint attorneys-in-fact or agents with power and authority,as defined or limited in their respective powers of attorney,for and on behalf of the Company to execute and deliver, and affix the seal of the Company thereto, bonds, undertakings, recognizances, consents of surety or other written obligations in the nature thereof and any of said officers may remove any such attorney-in-fact or agent and revoke the power and authority given to him. V(t rri : That any bond,undertaking,recognizance,consent of surety or written obligation in the nature thereof shall be valid and binding upon the Company when signed by the Chairman of the Board,the President,any Executive Vice President,any Senior Vice President,any Vice President or any Second Vice President and duly attested and sealed,if a seal is required,by the Corporate Secretary or any Department Secretary or any Assistant Corporate Secretary or any Assistant Department Secretary,or shall be valid and binding upon the Company when duly executed and sealed,if a seal is required,by a duly authorized attorney-in-fact or agent, pursuant to and within the limits of the authority granted,by'his or her power of attorney.=-' ' - This power of attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of THE TRAVELERS INDEMNITY COMPANY at a meeting duly called and held on the 1st day of November, 1985: VOTED: That the signature of any officer authorized by Resolutions of this Board and the Company seal may be affixed by facsimile to any power of attorney or special power of attorney or certification of either given for the execution of any bond, undertaking, recognizance or other written obligation in the nature thereof; such signature and seal, when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company,to be valid and binding upon the Company with the sante force and effect as though manually affixed. This power of attorney revokes any and all powers of attorney dated prior to November 1, 1985. IN WITNESS WHEREOF, THE TRAVELERS INDEMNITY COMPANY has caused these presents to be signed by its proper officer and its corporate seal to be hereunto affixed this 1st day of November 19 85 . THE TRAVELERS INDEMNITY COMPANY ‘NDEMM`%t 44, Att By# 4LIA-74 •••• SEAL ;:35 V�y•r ;; •••••• Secretary, Surety S . S-2242 Rev.9-85 Printed in U.S.A. (Over) Sate of Connecticut, Count of Hartford—ss: State Y On this 1st day of November in the year 19.86 before me personally came a L. Banta to me known, who, being by me duly sworn, did depose and say: that he resides in the State of Connecticut; that he is Secretary (Surety) of THE TRAVELERS INDEMNITY COMPANY, the corporation described in and which exe- cuted the above instrument;that he signed his name thereto by the.above quoted authority;that he knows the seal,of said corporation; that the seal affixed to said instrument is such corporate seal, and that it was so affixed by authority of his office under the by-laws of said corporation. •0 et). /P)—Licro. ' ; '1. 1 Notary Public / MECO. My commission expires April 1, 1988 CERTIFICATION I; Paul D. Tubach, Assistant Secretary (Surety) Of THE TRAVELERS INDEMNITY COMPANY, certify that the foregoing power of attorney, and the above quoted Resolutions of the Board of Directors of November 1, 1985 have not been abridged oi• revoked and a"re now in full force and effect. Signed and Sealed at Hartford, Connecticut, this 17th day of November 19 86 . 5St ,,% I/l2.. ck S 'E A L iceOg: 3 ; • • .,+ +!' Assistant Secretary, Surety • • -'S-2242 (BACK) II , Jk r_ •.� t4,57 ,- '�-?.t t,�,, < 1Z r;4 ,,¢¢ ,ii.:�t,, > , .N 1 -1 }-rpm ';....':17'; �'llyt - s,_;.4,n .0 n •*^- „.. o . ..,',.:r. ,. 'S''cc{ y F?'A 1c'` / : -- G-I t "r 11,;....;,..k.„,. _.r --^` ...„,k:..• --�- k,d�'v- � : 1 J�--aF r{ l•,� �pit M +1 �. � � �, � �, ;�. G 5:, ,; er'•. -;� >w f.�. +.�z� 1 '`,. �a,{' atm f 41 c, S:.7P.B�b` _i �Aii f.. •. .. � � '' -� t._ .,' E* r r '�,� � ISSUE DATE(M?/l/DD/YY) ; . Of I® CERTIFICATE OFA INSURANCE . -: �, * . 11- -86 • PRODUCER THiS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLYAND CONFERS _" _{, NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AMEND, 4, • William T. O'Brien Agency, Inc. EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. ,• 24225 W. Nine Mile Road - „L Southfield, Michigan 48034 COMPANIES AFFORDING COVERAGE 4 COMPANY A ''ti' LETTER Y -1' Travelers Ins. Co. ." COMPANY INSURED LETTER ISP kAluminum Building Corporation COMER Y C LETTER i 12280 Burt Road - COMPANY D Detroit, Michigan 48228 LETTER .%( +;r COMPANY ic iE 5: ; u. LETTER 1:'•""COVER•GES •F"r .:. ' '‘,.,..-....,----,iv ,' f.:• r + }THIS IS TO CERTIFY THAT POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. r;/ ;'"�s NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY • BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS,AND CONDI- =y'.- TIONS OF SUCH POLICIES. I.' '''Al CO POLICY EFFECTIVE POLICY ExPIRATION LIABILITY LIMITS IN THOUSANDS ` ,LTR TYPE OF INSURANCE POLICY NUMBER DATE(IppA y) OqTE(pIwDprYyi Elm EACHENCE �� - OCCURR d GENERAL UABILITY BODILY r-..t:.:4*'� A © COMPREHENSIVE FORM 11-24-86 11-24-87 INJURY $ 650-822A726-9-COF-86 ....:,..-74. PREMISES/OPERATiONS PROPERTY r• mUNDERGROUND DAMAGE $ ' r, EXPLOSION&COLLAPSE HAZARD .: 'iii ri PRODUCTS/COMPLETED OPERATIONS `�:, Fl CONTRACTUAL BtO6MBINPD ED $1 ,000 $1 ,000 - ,`;. C {4i�i,-rb ■ INDEPENDENT CONTRACTORS BROAD FORM PROPERTY DAMAGE :{, �'j ■ PERSONAL INJURY PERSONAL INJURY $ �: AUTOMOBILE UABILITY MOLT ,.e....,, ,-.,:i)', HAIRY X .s Vis- ,_ i,. ■ ANY AUTO PERSON) $ CT`:', .' f�-v v! r fa' S A ri ALL OWNED AUTOS(PRiV. PASS.) BODILY V :' ALL OWNED AUTOS OTHER THAM 650-822A]�6-9-COF-86 11-24-86 11-24-87J YT i= It PRIV.PASS. j ICO ENT) $ r s - + tirt il HIRED AUTOS ` ; '----:1,--,;.-,t _, . PROPERTY - :- PI NON-OWNED AUTOS DAMAGE $ :12..1,:-...,7,7,41:,`,*: ' .ILL,' M GARAGE LIABILITY - 7%+ rY tye}F BI 8 PD M v-.0-',,.'.:-:1:27::[-*--''' t ,;+' _ ,,. ;c7.,',, COMBINED $1 000 ::.'61---‘,..-.::'Z•:_6 f.,�L '',14 0w ' : ?;moi EXCESS UABILITY ;' '�:::vi INUMBRELLA FORM C 8 PD COMBINED $ $ qvA ■ OTHER THAN UMBRELLA FORM • , :,f' STATUTORY yr'':'n'r' `:i` :, WORKERS'COMPENSATION : ''',4-.ti ." $ (EACH ACCIDENT) - , AND `.‘.•1%,• ' $ (DISEASE-POLICY LIMIT) . t 'h>T EMPLOYERS' LIABILITY 1.:%. .. $ y-' IS�,;; OTHER - A. DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS f Central Park Tower, Elgin Illinois ILL 92-3 .14 ';CERTIFICATE HOLDER - _ - •-CANCELLATION' SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EX-ry . PIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO City o f E l g i n :: MAIL in DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE 150 Dexter Court - LEFT,BUT FAILURE TO MAiL SUCH NOTICEKINDSHALL ,-•- NO OBLIGATION OR LIABIIJTY Elgin, Illinois 60120 OF ANY KD E�@pIPANY, .� A ATIVES. - . "•. AUTHORIZED NTATIVE � •- '. ACORD 25-(8184) -3, F h t RIR/ACORD CORPORATION 1984 t! --'J-. rF w U c~--.J ' F VY y t-r f, r e,.t: ,- - y ..- ....�., t�3�'•t'r'�-".,1'`,�_ z+.'�...Svr�• t -,V.-_. .�.'..y -.7 .r>. s.}�acf?tt,. ,L:...,it '�.r , �.vt. *‘. ."..-'1..f- i. ..-1 _. , r a.i ,. ,•- 1.. .x._ G'E s .